[Federal Register Volume 76, Number 103 (Friday, May 27, 2011)]
[Rules and Regulations]
[Pages 30842-30855]
From the Federal Register Online via the Government Printing Office [www.gpo.gov]
[FR Doc No: 2011-12198]
=======================================================================
-----------------------------------------------------------------------
GENERAL SERVICES ADMINISTRATION
48 CFR Parts 501, 552, and 570
[GSAR Amendment 2011-01; GSAR Case 2006-G508 (Change 48) Docket 2009-
0017; Sequence 1]
RIN 3090-AI96
General Services Administration Acquisition Regulation; Rewrite
of Part 570; Acquiring Leasehold Interests in Real Property
AGENCY: Office of Acquisition Policy, General Services Administration
(GSA).
ACTION: Final rule.
-----------------------------------------------------------------------
SUMMARY: The General Services Administration (GSA) is amending the
General Services Administration Acquisition Regulation (GSAR) to revise
sections that provide requirements for acquiring leasehold interests in
real property.
DATES: Effective Date: June 27, 2011.
FOR FURTHER INFORMATION CONTACT: For clarification of content, contact
Ms.
[[Page 30843]]
Deborah Lague, Procurement Analyst, at (202) 694-8149. For information
pertaining to status or publication schedules, contact the Regulatory
Secretariat (MVCB), 1275 First Street, 7th Floor, Washington, DC 20417,
(202) 501-4755. Please cite GSAR Case 2006-G508.
SUPPLEMENTARY INFORMATION:
A. Background
On December 4, 2009, GSA published in the Federal Register at 74 FR
63704, a Proposed Rule with a request for comments. As a result, public
comments were received.
GSA is amended the GSAR subpart 501.106 by removing the reference
to ``570.702(c)'' and adding ``570.802(c)'' and ``570.802(d)'' in their
place.
GSA moved advertising requirements from Part 505 to section
570.106, Advertising, Publicizing, and Notifications to Congress, since
most of the guidance on advertising requirements contained in Part 505
relate to the leasing program. The changes to Part 505 have already
been implemented in GSAR case 2008-G503, published in the Federal
Register at 75 FR 32860, June 10, 2010.
GSA is amending the GSAR to revise GSAR Part 570, Acquiring
Leasehold Interests in Real Property. In summary, GSA is amending this
part to update regulatory provisions that are applicable to lease
transactions; to provide sustainability guidance on implementing
Executive Order 13514 and Guiding Principles for Federal Leadership in
High Performance and Sustainable Buildings; to delete the dollar value
of the simplified lease acquisition threshold and instead reference
Federal Acquisition Regulation (FAR) 2.101 for information about the
threshold; and to clarify the meaning and improve the readability of
this part. In addition, GSA is moving advertising requirements from
Part 505 to Part 570, since most of the guidance on advertising
requirements contained in Part 505 relate to the leasing program.
This rule revises GSAR 570 as follows:
Overall changes were made throughout the text to change ``you'' to
``contracting officer,'' and to edit language for clarity.
GSAR 570.101(b) is revised to delete GSAR rules that are no longer
applicable to the acquisition of leasehold interests in real property
and to add current references to GSAR 522.805, 522.807, and 532.111.
GSAR 570.101(c) is revised to update the GSAR provisions that are
applicable in leasing transactions. This section is revised to delete
GSAM sections from the GSAR and move them to the GSAM, the non-
regulatory portion of the manual.
GSAR 570.101(d) is added to explain that the FAR does not apply to
leasehold acquisitions of real property and to further explain that
references to the FAR in Part 570 are used as a matter of policy where
the underlying statute behind the FAR provision applies to leasing or
as matter of administrative convenience.
GSAR 570.102 is revised to add definitions for ``ANSI/BOMA Office
Area (ABOA)'', ``lease acquisition,'' ``lease extension,'' ``lease
renewal (option),'' ``succeeding lease,'' and ``superseding lease.''
The definition for ``simplified lease acquisition threshold'' is
revised to delete the dollar value, and instead reference FAR 2.101 for
information about the threshold. The definition for ``small business''
is revised to delete the dollar limit for annual average gross receipts
and to reference the size standard established by the Small Business
Administration. Further revisions were made to include where the size
standards may be found on the web. The definition of ``rent and related
services'' is deleted because it is not used within the subpart. The
definition for ``space in buildings'' is deleted because this
definition was only referenced at 570.105-3 which is also being
deleted.
GSAR 570.103 is revised to update the statutory reference to
leasing authority. In addition, GSAR 570.103 is revised, consistent
with statute and regulation, to allow the contracting officer to
designate a contracting officer's representative.
GSAR 570.105-2 is re-titled, Criteria for the Use of Two-phase
Design-build. GSAR 570.105-2 is revised to update the statutory
reference to leasing authority. GSAR 570.105-2(c) is added to reference
570.305, where additional procedures can be found regarding two-phase
design-build selections that apply to acquisition of leasehold
interests.
GSAR 570.105-3 is deleted in its entirety because sealed bidding is
not used in GSA leasing transactions. Since negotiations or discussions
are not allowed under sealed bidding, GSA has determined that the use
of negotiated acquisition procedures in real property lease
acquisitions enables GSA to clarify and explain SFO requirements to
more effectively address the unique elements of each property and
obtain better lease pricing.
GSAR 570.106 is re-titled Advertising, Publicizing, and
Notifications to Congress, and revised to incorporate advertising
requirements from Part 505, because most of the exceptions to
advertising requirements contained in Part 505 relate to the leasing
program.
GSAR 570.106-1, Synopsis of Lease Awards, is added to incorporate
synopsizing requirements of lease awards from Part 505.
GSAR 570.108 is revised to update reference to ``Excluded Parties
List System'' (EPLS).
GSAR 570.109 is revised to add the language ``representations and''
for clarification.
GSAR 570.110 is revised to require the contracting officer to
obtain two bids or cost and pricing data for price analysis of offered
tenant improvement costs.
GSAR 570.111 is revised to require that the inspection and
acceptance document contain the ANSI/BOMA Office Area (ABOA) square
footage accepted and the acceptance date.
GSAR 570.115, Novation and Change of Ownership, is added to include
language stating that FAR 42.12 applies in the event of a transfer of
ownership of the leased premises or a change in the lessor's legal
name.
GSAR 570.116, Contract Format, is added to include language stating
that the uniform contract format is not required for leases of real
property.
GSAR 570.117, Sustainable Requirements for Lease Acquisitions, is
added to add a requirement for the contracting officer to include
sustainable design requirements appropriate for the type of leasing
action in the solicitations for offers, to identify the location of
solicitation requirements and instructions on http://www.gsa.gov/leasing, and to include guidance on Executive Order 13514 and the
Guiding Principles for Federal Leadership in High Performance and
Sustainable Buildings.
GSAR 570.203-3(a), is revised to add a reference to ``GSA Form
3626'' for clarity and to require the contracting officer to include
sustainable design requirements in offers.
GSAR 570.203-4 is revised to include a reference to the thresholds
at FAR 15.403-4 and 19.702(a). It is further revised to require that
the contracting officer make an affirmative determination of price
reasonableness.
GSAR Subpart 570.3 is renamed Acquisition Procedures for Leasehold
Interests in Real Property Over the Simplified Lease Acquisition
Threshold.
GSAR 570.303-1 is revised to add a requirement that each
Solicitation for Offers (SFO) must include sustainable design
requirements.
GSAR 570.303-2 is revised to allow electronic issuance of
solicitations.
GSAR 570.303-4 is revised to require contracting officers to re-
advertise and
[[Page 30844]]
reissue a solicitation when a complete revision of a solicitation is
required in accordance with GSAR 570.106.
GSAR 570.304 is revised to adequately distinguish between best
value and low price technically acceptable acquisitions.
GSAR 570.305 is revised to require the contracting officer to
consider planned subcontracting opportunities for small disadvantaged
business concerns during phase one evaluations.
GSAR 570.306(b) is revised to require the contracting officer to
review the elements of the lessor's proposed rent to analyze whether
the individual elements are realistic and reflect the lessor's
understanding of work to be performed. GSAR 570.306(c) is revised to
add information on past performance evaluations. GSAR 570.306(f) was
revised to direct the reader to important paragraphs in Part 570
concerning the evaluation of offers.
GSAR 570.401 is revised to add language indicating that if a
renewal option was not evaluated as part of the lease at award, then
the addition of a renewal option during the lease term must satisfy the
requirements of GSAM 506 regarding full and open competition.
GSAR 570.402-2 is revised to update the reference to publication
and advertising requirements for leases.
GSAR 570.404 is revised to clarify that a superseding lease may be
used when market conditions warrant renegotiation of an existing lease,
and to provide considerations of a cost benefit analysis.
GSAR 570.405 is revised to provide examples of situations where
lease extensions may be appropriate.
GSAR 570.501(a) is revised to explain that the procedures in
570.502 apply to alterations acquired directly from a lessor by
modification or supplemental lease agreement.
GSAR 570.502 is deleted because this information is addressed in
570.501(a).
GSAR 570.502-1 is revised to tie the threshold to the FAR
definition of the micro-purchase threshold.
GSAR 570.502-2 is revised to delete language referencing progress
payments. This section is further revised to allow the lease
contracting officer to delegate alteration contracting authority to a
warranted contracting officer's representative in GSA or the tenant
agency.
GSAR 570.503 is revised to delete paragraph (b) from the GSAM and
incorporate it into the GSAR.
New section GSAR 570.6 Contracting for Overtime Services and
Utilities in Leases is added to provide requirements for when overtime
services and utilities are needed.
GSAR 570.601 is renumbered as 570.701 and is revised to delete the
reference to the dollar value of the thresholds, and to instead provide
the FAR reference because the thresholds may change. GSAR 570.601 is
revised to include the following additional FAR provisions or clauses
that must be included in solicitations:
52.204-6, Data Universal Numbering system (DUNS) Number;
52.204-7, Central Contractor Registration;
52.219-28, Post-Award Small Business Program Rerepresentation (use
if lease term exceeds five years),
52.232-33, Electronic Funds Transfer--Central Contractor
Registration;
52.222-36, Affirmative Action for Workers with Disabilities;
52.204-10, Reporting Executive Compensation and First-Tier
Subcontract Awards;
52.204-5, Women-Owned Business (Other than Small Business);
52.203-13, Contractor Code of Business Ethics and Conduct;
52.203-14, Display of Hotline Poster(s).
GSAR 570.602 and 570.603 are renumbered as 570.702 and 703,
respectively, and are revised to require the contracting officer to
document the file when deleting or substantially changing a clause.
GSAR 570.603 is further revised to number the paragraphs (a) and (b),
and to include language in paragraphs (a) and (b) to require the
contracting officer to include the following additional clauses in
leaseholds for real property:
552.215-70, Examination of Records by GSA;
552.270-28, Mutuality of Obligation;
552.270-29, Acceptance of Space;
552.270-30, Price Adjustment for Illegal or Improper Activity;
552.270-31, Prompt Payment;
552.270-32, Covenant Against Contingent Fees.
GSAR 570.604 is renumbered as 570.704 and is revised to delete the
reference to clause 552.203-5, Covenant Against Contingent Fees,
because the updated clause number is now referenced in 570.703.
GSAR 570.701 is renumbered as 570.801 and is revised to delete the
instructions to omit the reference to Standard Form (SF)2-A.
GSAR 570.802(d) is added to allow the use of the GSA Form 1217,
Lessor's Annual Cost Statement, to obtain pricing information regarding
offered services and lease commissions.
The clause at 552.270-1, Instructions to Offerors--Acquisition
Leasehold Interest in Real Property, is revised to add language
requiring execution and delivery of a lease to effectuate contract
formation. It also adds paragraph (f) to address paperwork collection
information.
The provision at 552.270-3, Parties to Execute Leases, is revised
to make it consistent with the instructions contained in FAR 4.102.
The clause at 552.270-7, Fire and Casualty Damage, is revised to
permit the government to assess a property's condition before giving
notice of termination.
The clause at 552.270-14, Changes, is revised to change ``usable
square foot'' to ``ABOA square foot,'' and to specify the impact of the
failure to assert a claim for a price adjustment.
The clause at 552.270-16, Adjustment for Vacant Premises, is
revised to clarify when and how adjustments for vacant premises will be
made.
The clause at 552.270-18, Default in Delivery--Time Extensions, is
revised to update the terminology of ``usable square footage'' to
``ABOA square footage.''
The clause at 552.270-20, Payment, is revised to update the
terminology of ``usable square footage'' to ``ABOA square footage.''
The clause at 552.270-29, Acceptance of Space, is revised to update
the terminology of ``usable square footage'' to ``ABOA square footage''
and to simplify the reference to a section in the solicitation.
The following clauses were added to GSAR Part 570: 552.270-30,
Price Adjustment for Illegal or Improper Activity; 552.270-31, Prompt
Payment; and 552.270-32, Covenant Against Contingent Fees.
B. Discussion of Comments
Two public comments from one respondent were received in response
to the proposed rule.
Comment: One comment recommended deleting the language ``and
delivery'' at GSAR 552.270-1(e)(7), Instructions to Offerors.
Response: Do not concur. Execution and delivery in the legal sense
are both necessary elements to effectuate the contract. Absent
delivery, the offeror would not know that the contract was executed and
that the offeror was bound to perform.
Comment: The second comment recommended at GSAM 570.106-1(c), for
the posting of a justification for other than full and open competition
on the FedBizOpps website, be revised to clarify when the justification
is to be posted.
[[Page 30845]]
Response: Do not concur. Justifications for other than full and
open are required to be posted after award by Section 844 of the
National Defense Authorization Act for Fiscal Year 2008, ``Public
Disclosure of Justification and Approval Documents for Noncompetitive
Contracts''. Parties receive notice of the opportunity to express
interest in the leasing action by posting of the notice required by
section GSAM 570.402-2 of the proposed regulation.
C. Executive Orders 12866 and 13563
This is not a significant regulatory action and, therefore, was not
subject to review under Section 6(b) of Executive Order 12866,
Regulatory Planning and Review, dated September 30, 1993. This rule is
not a major rule under 5 U.S.C. 804.
In accordance with Executive Order 13563, Improving Regulation and
Regulatory Review, dated January 18, 2011, GSA determined that this
rule is not excessively burdensome to the public, and is consistent
with amending the General Services Administration Acquisition
Regulation (GSAR) to revise GSAR Part 570, Acquiring Leasehold
Interests in Real Property.
D. Regulatory Flexibility Act
The General Services Administration certifies that this final rule
will not have a significant economic impact on a substantial number of
small entities within the meaning of the Regulatory Flexibility Act, 5
U.S.C. 601, et seq., because the rule is not considered substantive. It
clarifies existing language, deletes obsolete coverage, and edits
existing language.
E. Paperwork Reduction Act
The Paperwork Reduction Act does apply; however, these changes to
the GSAR do not impose additional information collection requirements
to the paperwork burden previously approved under OMB Control Number
3090-0086.
The Paperwork Reduction Act applies because the rule contains
information collection requirements. Accordingly, the Regulatory
Secretariat has forwarded a request to receive approval of the new
information collection requirement concerning GSAR Case 2006-G508,
Acquiring Leasehold Interests in Real Property, to the Office of
Management and Budget under 44 U.S.C. 3501, et seq.
Annual Reporting Burden
At 570.702(d), the contracting officer may use GSA Form 1217,
Lessor's Annual Cost Statement, to obtain pricing information regarding
offered services and lease commissions.
The annual reporting burden is estimated as follows:
Respondents: 5,733.
Responses per respondent: 1.
Total annual responses: 5,733.
Preparation hours per response: 1 hour.
Total response burden hours: 5,733.
Public reporting burden for this collection of information is
estimated to average 1 hour per response, including the time for
reviewing instructions, searching existing data sources, gathering and
maintaining the data needed, and completing and reviewing the
collection of information.
List of Subjects in 48 CFR Parts 501, 552, and 570
Government procurement.
Dated: May 12, 2011.
Rodney P. Lantier,
Deputy Director, Office of Acquisition Policy.
Therefore, GSA amends 48 CFR parts 501, 552, and 570 as set forth
below:
0
1. The authority citation for 48 CFR parts 501, 552, and 570 continues
to read as follows:
Authority: 40 U.S.C. 121(c).
PART 501--GENERAL SERVICES ADMINISTRATION ACQUISITION REGULATION
SYSTEM
501.106 [Amended]
0
2. Amend section 501.106 by removing from the table the entry
``570.702(c)'' and adding the entries ``570.802(c)'' and ``570.802(d)''
in its place to read as follows:
501.106 OMB Approval under the Paperwork Reduction Act.
------------------------------------------------------------------------
OMB control
GSAR reference No.
------------------------------------------------------------------------
* * * * *
570.802(c).............................................. 3090-0086
570.802(d).............................................. 3090-0086
------------------------------------------------------------------------
PART 552--SOLICITATION PROVISIONS AND CONTRACT CLAUSES
0
3. Amend section 552.270-1 by--
0
a. Removing from the introductory text ``570.602'' and adding
``570.702'' in its place;
0
b. Removing from the introductory text ``MAR 1998'' and adding ``JUN
2011'' in its place;
0
c. Removing from paragraph (a) in the definition heading, ``In Writing
or Written'' and adding ``In writing, writing or written'' in its
place, and removing ``which'' and adding ``that'' in its place;
0
d. Removing from paragraph (c)(2)(i)(A) ``5th'' and adding ``fifth'' in
its place;
0
e. Adding in paragraph (c)(2)(i)(E) the word ``that'' before ``the
Contracting Officer'';
0
f. Revising paragraph (e)(7);
0
g. Adding paragraph (f); and
0
h. Removing from Alternates I and II ``570.602'' and adding ``570.702''
in their place.
The newly added and revised text reads as follows:
552.270-1 Instructions to Offerors--Acquisition of Leasehold Interests
in Real Property.
* * * * *
(e) * * *
(7) The execution and delivery of the Lease contract by the
Government establishes a valid award and contract.
* * * * *
(f) Paperwork collection. The information collection requirements
contained in this solicitation/contract are either required by
regulation or approved by the Office of Management and Budget pursuant
to the Paperwork Reduction Act and assigned OMB Control No. 3090-0163.
* * * * *
552.270-2 [Amended]
0
4. Amend section 552.270-2 by removing from the introductory text
``570.602'' and adding ``570.702'' in its place.
0
5. Amend section 552.270-3 by--
0
a. Removing from the introductory text ``570.602'' and adding
``570.702'' in its place;
0
b. Removing from the date of the provision ``Sep 1999'' and adding
``JUN 2011'' in its place;
0
c. Revising paragraph (a);
0
d. Removing from paragraph (b) ``shall be signed with'' and adding
``must be signed in'' in its place, and removing ``, if requested by
the government,'';
0
e. Removing from paragraph (c) ``shall be signed with'' and adding
``must be signed in'' in its place; and
0
f. Adding paragraphs (d) and (e).
The revised and added text reads as follows:
552.270-3 Parties to Execute Lease.
* * * * *
(a) If the lessor is an individual, that individual shall sign
the lease. A lease with an individual doing business as a firm shall
be signed by that individual, and the signature shall be followed by
the individual's typed, stamped, or printed name and the words, ``an
individual doing business as ------ [insert name of firm].''
* * * * *
(d) If the Lessor is a joint venture, the lease must be signed
by each participant in the
[[Page 30846]]
joint venture in the manner prescribed in paragraphs (a) through (c)
of this provision for each type of participant. When a corporation
is participating in the joint venture, the corporation shall provide
evidence that the corporation is authorized to participate in the
joint venture.
(e) If the lease is executed by an attorney, agent, or trustee
on behalf of the Lessor, an authenticated copy of the power of
attorney, or other evidence to act on behalf of the Lessor, must
accompany the lease.
* * * * *
0
6. Amend section 552.270-4 by--
0
a. Removing from the introductory text ``570.603'' and adding
``570.703'' in its place;
0
b. Removing paragraph (l); and
0
c. Redesignating paragraphs (a) through (k) as (b) through (l)
respectively; and adding a new paragraph (a).
The newly added text reads as follows:
552.270-4 Definitions.
* * * * *
(a) ANSI/BOMA Office Area (ABOA) means the area ``where a tenant
normally houses personnel, and/or furniture, for which a measurement
is to be computed,'' as stated by the American National Standards
Institute/Building Owners and Managers Association (ANSI/BOMA)
publication, Z65.1-1996.
* * * * *
552.270-5 [Amended]
0
7a. Amend section 552.270-5 in the introductory text by removing
``570.603'' and adding ``570.703'' in their place.
552.270-6 [Amended]
0
7b. Amend section 552.270-6 in the introductory text by removing
``570.603'' and adding ``570.703'' in their place.
552.270-7 [Amended]
0
8. Amend section 552.270-7 by--
0
a. Removing from the introductory text ``570.603'' and adding
``570.703'' in its place;
0
b. Removing from the date of the clause ``Sep 1999'' and adding ``JUN
2011'' in its place; and
0
c. Removing ``of the fire or other casualty'' and adding ``after such
determination'' in its place.
552.270-8 [Amended]
0
9a. Amend section 552.270-8 in the introductory text by removing
``570.603'' and adding ``570.703'' in its place.
552.270-9 [Amended]
0
9b. Amend section 552.270-9 in the introductory text by removing
``570.603'' and adding ``570.703'' in its place.
552.270-10 [Amended]
0
9c. Amend section 552.270-10 in the introductory text by removing
``570.603'' and adding ``570.703'' in its place.
552.270-11 [Amended]
0
9d. Amend section 552.270-11 in the introductory text by removing
``570.603'' and adding ``570.703'' in its place.
552.270-12 [Amended]
0
9e. Amend section 552.270-12 in the introductory text by removing
``570.603'' and adding ``570.703'' in its place.
552.270-13 [Amended]
0
9f. Amend section 552.270-13 in the introductory text by removing
``570.603'' and adding ``570.703'' in its place.
0
10. Amend section 552.270-14 by--
0
a. Removing from the introductory text ``570.603'' and adding
``570.703'' in its place, and removing ``Sep 1999'' and adding ``Jun
2011'' in its place;
0
b. Removing from paragraph (b)(4) ``usable'' and adding ``ABOA'' in its
place; and
0
c. Adding a new sentence to paragraph (c) after the first sentence.
The added text reads as follows:
552.270-14 Changes.
* * * * *
(c) * * * The Lessor's failure to assert its right for adjustment
within the time frame specified herein shall be a waiver of the
Lessor's right to an adjustment under this paragraph. * * *
* * * * *
552.270-15 [Amended]
0
11. Amend section 552.270-15 by removing ``570.603'' and adding
``570.703'' in its place.
0
12. Revise section 552.270-16 to read as follows:
552.270-16 Adjustment for Vacant Premises.
As prescribed in 570.703, insert the following clause:
Adjustment for Vacant Premises (JUN 2011)
(a) If the Government fails to occupy any portion of the leased
premises or vacates the premises in whole or in part before the
lease term expires, the rental rate will be reduced. The reduction
shall occur after the Government gives 30 calendar days notice to
the Lessor, and shall continue in effect until the Government
occupies or reoccupies the vacant premises or the lease expires or
is terminated.
(b) The rate will be reduced by that portion of the costs per
ABOA square foot of operating expenses not required to maintain the
space. In addition, at the first operating cost adjustment after the
notice of reduction to the rent, the base cost of services subject
to escalation will be reduced by said amount. In the event that the
Government occupies or reoccupies the vacant premises on the lease
anniversary date following the occupation of the vacant premises,
the base cost of services subject to escalation will be increased by
said amount.
(c) The reduction in operating costs shall be negotiated and
stated in the lease.
(End of clause)
552.270-17 [Amended]
0
13. Amend section 552.270-17 in the introductory text by removing
``570.603'' and adding ``570.703'' in its place.
552.270-18 [Amended]
0
14. Amend section 552.270-18 in the introductory text by removing
``570.603'' and adding ``570.703'' in its place and removing from
paragraph (c) ``usable'' and adding ``ABOA'' in its place.
552.270-19 [Amended]
0
15. Amend section 552.270-19 by removing ``570.603'' and adding
``570.703'' in its place.
552.270-20 [Amended]
0
16. Amend section 552.270-20 by--
0
a. Removing from the introductory text ``570.603'' and adding
``570.703'' in its place;
0
b. Removing from paragraphs (a), (b), and (c) ``usable'' and adding
``ABOA'' in its place five times; and
0
c. Removing from paragraph (c) ``Usable'' and adding ``ABOA'' in its
place, and removing ``USF'' two times.
552.270-21 [Amended]
0
17a. Amend section 552.270-21 in the introductory text by removing
``570.603'' and adding ``570.703'' in its place.
552.270-22 [Amended]
0
17b. Amend section 552.270-22 in the introductory text by removing
``570.603'' and adding ``570.703'' in its place.
552.270-23 [Amended]
0
17c. Amend section 552.270-23 in the introductory text by removing
``570.603'' and adding ``570.703'' in its place.
552.270-24 [Amended]
0
17d. Amend section 552.270-24 in the introductory text by removing
[[Page 30847]]
``570.603'' and adding ``570.703'' in its place.
552.270-25 [Amended]
0
17e. Amend section 552.270-25 in the introductory text by removing
``570.603'' and adding ``570.703'' in its place.
552.270-26 [Amended]
0
17f. Amend section 552.270-26 in the introductory text by removing
``570.603'' and adding ``570.703'' in its place.
552.270-27 [Amended]
0
17g. Amend section 552.270-27 in the introductory text by removing
``570.603'' and adding ``570.703'' in its place.
552.270-28 [Amended]
0
17h. Amend section 552.270-28 in the introductory text by removing
``570.603'' and adding ``570.703'' in its place.
552.270-29 [Amended]
0
18. Amend section 552.270-29 by--
0
a. Removing from the introductory text ``570.603'' and adding
``570.703'' in its place;
0
b. Removing from date of the clause ``Sep 1999'' and adding ``Jun
2011'' in its place; and
0
c. Amending paragraph (b) by removing ``usable square footage as
indicated in Paragraph 1.1, Amount and Type of Space, of this
solicitation'' and adding ``ABOA square footage as indicated in the
solicitation paragraph, Amount and Type of Space'' in its place.
0
19. Add new sections 552.270-30, 552.270-31, and 552.270-32 to read as
follows:
552.270-30 Price Adjustment for Illegal or Improper Activity.
As prescribed in 570.703, insert the following clause:
Price Adjustment for Illegal or Improper Activity (JUN 2011)
(a) If the head of the contracting activity (HCA) or his or her
designee determines that there was a violation of subsection 27(a)
of the Office of Federal Procurement Policy Act, as amended (41
U.S.C. 423), as implemented in the Federal Acquisition Regulation,
the Government, at its election, may--
(1) Reduce the monthly rental under this lease by five percent
of the amount of the rental for each month of the remaining term of
the lease, including any option periods, and recover five percent of
the rental already paid;
(2) Reduce payments for alterations not included in monthly
rental payments by five percent of the amount of the alterations
agreement; or
(3) Reduce the payments for violations by a Lessor's
subcontractor by an amount not to exceed the amount of profit or fee
reflected in the subcontract at the time the subcontract was placed.
(b) Prior to making a determination as set forth above, the HCA
or designee shall provide to the Lessor a written notice of the
action being considered and the basis thereof. The Lessor shall have
a period determined by the agency head or designee, but not less
than 30 calendar days after receipt of such notice, to submit in
person, in writing, or through a representative, information and
argument in opposition to the proposed reduction. The agency head or
designee may, upon good cause shown, determine to deduct less than
the above amounts from payments.
(c) The rights and remedies of the Government specified herein
are not exclusive, and are in addition to any other rights and
remedies provided by law or under this lease.
(End of clause)
552.270-31 Prompt Payment.
As prescribed in 570.703, insert the following clause:
Prompt Payment (JUN 2011)
The Government will make payments under the terms and conditions
specified in this clause. Payment shall be considered as being made
on the day a check is dated or an electronic funds transfer is made.
All days referred to in this clause are calendar days, unless
otherwise specified.
(a) Payment due date--(1) Rental payments. Rent shall be paid
monthly in arrears and will be due on the first workday of each
month, and only as provided for by the lease.
(i) When the date for commencement of rent falls on the 15th day
of the month or earlier, the initial monthly rental payment under
this contract shall become due on the first workday of the month
following the month in which the commencement of the rent is
effective.
(ii) When the date for commencement of rent falls after the 15th
day of the month, the initial monthly rental payment under this
contract shall become due on the first workday of the second month
following the month in which the commencement of the rent is
effective.
(2) Other payments. The due date for making payments other than
rent shall be the later of the following two events:
(i) The 30th day after the designated billing office has
received a proper invoice from the Contractor.
(ii) The 30th day after Government acceptance of the work or
service. However, if the designated billing office fails to annotate
the invoice with the actual date of receipt, the invoice payment due
date shall be deemed to be the 30th day after the Contractor's
invoice is dated, provided a proper invoice is received and there is
no disagreement over quantity, quality, or Contractor compliance
with contract requirements.
(b) Invoice and inspection requirements for payments other than
rent. (1) The Contractor shall prepare and submit an invoice to the
designated billing office after completion of the work. A proper
invoice shall include the following items:
(i) Name and address of the Contractor.
(ii) Invoice date.
(iii) Lease number.
(iv) Government's order number or other authorization.
(v) Description, price, and quantity of work or services
delivered.
(vi) Name and address of Contractor official to whom payment is
to be sent (must be the same as that in the remittance address in
the lease or the order).
(vii) Name (where practicable), title, phone number, and mailing
address of person to be notified in the event of a defective
invoice.
(2) The Government will inspect and determine the acceptability
of the work performed or services delivered within seven days after
the receipt of a proper invoice or notification of completion of the
work or services unless a different period is specified at the time
the order is placed. If actual acceptance occurs later, for the
purpose of determining the payment due date and calculation of
interest, acceptance will be deemed to occur on the last day of the
seven day inspection period. If the work or service is rejected for
failure to conform to the technical requirements of the contract,
the seven days will be counted beginning with receipt of a new
invoice or notification. In either case, the Contractor is not
entitled to any payment or interest unless actual acceptance by the
Government occurs.
(c) Interest Penalty. (1) An interest penalty shall be paid
automatically by the Government, without request from the
Contractor, if payment is not made by the due date.
(2) The interest penalty shall be at the rate established by the
Secretary of the Treasury under Section 12 of the Contract Disputes
Act of 1978 (41 U.S.C. 611) that is in effect on the day after the
due date. This rate is referred to as the ``Renegotiation Board
Interest Rate,'' and it is published in the Federal Register
semiannually on or about January 1 and July 1. The interest penalty
shall accrue daily on the payment amount approved by the Government
and be compounded in 30-day increments inclusive from the first day
after the due date through the payment date.
(3) Interest penalties will not continue to accrue after the
filing of a claim for such penalties under the clause at 52.233-1,
Disputes, or for more than one year. Interest penalties of less than
$1.00 need not be paid.
(4) Interest penalties are not required on payment delays due to
disagreement between the Government and Contractor over the payment
amount or other issues involving contract compliance or on amounts
temporarily withheld or retained in accordance with the terms of the
contract. Claims involving disputes, and any interest that may be
payable, will be resolved in accordance with the clause at 52.233-1,
Disputes.
(d) Overpayments. If the Lessor becomes aware of a duplicate
payment or that the Government has otherwise overpaid on a payment,
the Contractor shall--
[[Page 30848]]
(1) Return the overpayment amount to the payment office cited in
the contract along with a description of the overpayment including
the--
(i) Circumstances of the overpayment (e.g., duplicate payment,
erroneous payment, liquidation errors, date(s) of overpayment);
(ii) Affected lease number;
(iii) Affected lease line item or subline item, if applicable;
and
(iv) Lessor point of contact.
(2) Provide a copy of the remittance and supporting
documentation to the Contracting Officer.
(End of clause)
Alternate I (Sep 1999). If Alternate I is used, subparagraph (a)(1)
of the basic clause should be designated as paragraph (a) and
subparagraph (a)(2) and paragraph (b) should be deleted. Paragraph (c)
of the basic clause should be redesignated as (b).
552.270-32 Covenant Against Contingent Fees.
As prescribed in 570.703, insert the following clause:
Covenant Against Contingent Fees (JUN 2011)
(a) The Contractor warrants that no person or agency has been
employed or retained to solicit or obtain this contract upon an
agreement or understanding for a contingent fee, except a bona fide
employee or agency. For breach or violation of this warranty, the
Government shall have the right to annul this contract without
liability or, in its discretion, to deduct from the contract price
or consideration, or otherwise recover the full amount of the
contingent fee.
(b) Bona fide agency, as used in this clause, means an
established commercial or selling agency (including licensed real
estate agents or brokers), maintained by a Contractor for the
purpose of securing business, that neither exerts nor proposes to
exert improper influence to solicit or obtain Government contracts
nor holds itself out as being able to obtain any Government contract
or contracts through improper influence.
Bona fide employee, as used in this clause, means a person,
employed by a Contractor and subject to the Contractor's supervision
and control as to time, place, and manner of performance, who
neither exerts nor proposes to exert improper influence to solicit
or obtain Government contracts nor holds out as being able to obtain
any Government contract or contracts through improper influence.
Contingent fee, as used in this clause, means any commission,
percentage, brokerage, or other fee that is contingent upon the
success that a person or concern has in securing a Government
contract.
Improper influence, as used in this clause, means any influence
that induces or tends to induce a Government employee or officer to
give consideration or to act regarding a Government contract on any
basis other than the merits of the matter.
(End of clause)
PART 570--ACQUIRING LEASEHOLD INTERESTS IN REAL PROPERTY
0
20. Amend section 570.101 by--
0
a. Removing from paragraph (b), from the table, ``504.5'', ``505'',
``514.201-7(b)'', ``515.204-1'', ``522.8'', ``532.1'', and ``532.908''
and adding, in numerical order, ``522.805'', ``522.807'', and
``532.111'', respectively; and
0
b. Adding a paragraph (d).
The added text reads as follows:
570.101 Applicability.
* * * * *
(d) The FAR does not apply to leasehold acquisitions of real
property. Where referenced in this part, FAR provisions have been
adopted based on a statutory requirement applicable to such lease
acquisitions or as a matter of policy, including, but not limited to
``Federal agency procurement'' as defined at FAR 3.104.
0
21. Amend section 570.102 by--
0
a. Removing the definition ``Acquisition'';
0
b. Adding, in alphabetical order, the definition ``ANSI/BOMA Office
Area (ABOA)'';
0
c. Adding, in alphabetical order, the definition ``Lease acquisition'';
0
d. Adding, in alphabetical order, the definition ``Lease extension'';
0
e. Adding, in alphabetical order, the definition ``Lease renewal
(option)'';
0
f. Removing the definition ``Rent and related services'';
0
g. Revising the definition ``Simplified lease acquisition threshold'';
0
h. Revising the definition ``Small business'';
0
i. Revising the definition ``Solicitation for Offers (SFO)'';
0
j. Removing the definition ``Space in buildings'';
0
k. Removing from the definition ``Substantially as follows'' or
``substantially the same as,'' the word ``you'' and adding ``the
contracting officer'' in its place.
0
l. Adding, in alphabetical order, the definition ``Succeeding lease'';
and
0
m. Adding, in alphabetical order, the definition ``Superseding lease''.
The added and revised text reads as follows:
570.102 Definitions.
ANSI/BOMA Office Area (ABOA) means the area ``where a tenant
normally houses personnel, and/or furniture, for which a measurement is
to be computed,'' as stated by the American National Standards
Institute/Building Owners and Managers Association (ANSI/BOMA)
publication, Z65.1-1996.
* * * * *
Lease acquisition means the acquiring by lease of an interest in
improved real property for use by the Government, whether the space
already exists or must be constructed.
Lease extension means extension of the expiration date of a lease
to provide for continued occupancy on a short term basis.
Lease renewal (option) means the right, but not the obligation of
the Government to continue a lease upon specified terms and conditions,
including lease term and rent.
* * * * *
Simplified lease acquisition threshold means the simplified
acquisition threshold (see FAR 2.101), when applied to the average
annual amount of rent for the term of the lease, including option
periods and excluding the cost of services.
Small business means a concern including affiliates, which is
organized for profit, is independently-owned and operated, is not
dominant in the field of leasing commercial real estate, and that has
annual average gross receipts for the preceding three fiscal years
which are less than the size standard established by the Small Business
Administration pursuant to 13 CFR Part 121. The size standards may be
found at http://www.sba.gov/size/sizetable_2002.html. For most lease
procurements, the NAICS code is 531190.
Solicitation for Offers (SFO) means a request for proposals.
* * * * *
Succeeding lease means a lease whose effective date immediately
follows the expiration date of an existing lease for space in the same
building.
Superseding lease means a lease that replaces an existing lease,
prior to the scheduled expiration of the existing lease term.
0
22. Revise section 570.103 to read as follows:
570.103 Authority to lease.
(a) The Administrator of General Services is authorized by 40
U.S.C. Sec. 585 to enter into a lease agreement for the accommodation
of a Federal agency in a building (or improvement) which is in
existence or being erected by the lessor for the accommodation of the
Federal agency. The lease agreement may not bind the Government for
more than 20 years.
(b) The contracting officer has exclusive authority to enter into
and administer leases on the Government's behalf to the extent provided
in the certificate of appointment as a contracting officer. Nothing in
this paragraph is intended to limit the
[[Page 30849]]
contracting officer's authority to designate, consistent with statute
and regulation, a contracting officer's representative.
570.104 [Amended]
0
23. Amend section 570.104 by removing ``you use'' and adding ``the
contracting officer uses'' in its place.
0
24. Revise section 570.105-1 to read as follows:
570.105-1 Contracting by negotiation.
Contracting by negotiation is appropriate for acquiring space in a
building through a lease contract. The contracting officer will usually
need to conduct discussions with offerors about their proposals and
consider factors other than price in making the award.
0
25. Amend section 570.105-2 by--
0
a. Revising the section heading;
0
b. Revising the introductory text;
0
c. Removing from paragraph (a) ``You anticipate'' and adding ``The
contracting officer anticipates that'' in its place, and removing
``public'';
0
d. Removing from the introductory text of paragraph (b) ``You
determine'' and adding ``The contracting officer determines whether''
in its place;
0
e. Removing from paragraph (b)(1) ``You expect'' and adding ``The
contracting officer expects'' in its place;
0
f. Removing from paragraph (b)(4) ``You consider'' and adding ``The
contracting officer considers'' in its place;
0
g. Redesignating paragraphs (b)(4)(iv) through (b)(4)(vi) as paragraphs
(b)(4)(v) through (b)(4)(vii), respectively, and adding a new paragraph
(b)(4)(iv); and
0
h. Adding paragraph (c).
The revised and added text reads as follows:
570.105-2 Criteria for the use of two-phase design-build.
The contracting officer may use the two-phase design-build
selection procedures in 41 U.S.C. 253m for lease construction projects.
This includes lease construction projects with options to purchase the
real property leased. Use the procedures in 41 U.S.C. 253m and FAR 36.3
when the conditions in (a) and (b) below are met:
* * * * *
(b) * * *
(4) * * *
(iv) The past performance of potential contractors.
* * * * *
(c) See 570.305 for additional information.
570.105-3 [Removed]
0
26. Remove section 570.105-3.
0
27a. Revise section 570.106 to read as follows:
570.106 Advertising, publicizing, and notifications to Congress.
(a) If a proposed acquisition is not exempt under FAR 5.202 or GSAR
570.106(e), and is for a leasehold interest in real property estimated
to exceed 10,000 square feet, then the contracting officer must
publicize the proposed acquisition in http://www.FBO.gov.
(b) For leasehold acquisitions where the solicitation requires the
construction of a new building on a preselected site, the contracting
officer, in accordance with the timeframes established in FAR 5.203,
must publicize the proposed acquisition in http://www.FBO.gov
regardless of size or value.
(c) For leasehold acquisitions not subject to a square foot
measurement (e.g., antennas, piers, parking), contracting officers must
publicize the proposed acquisition in http://www.FBO.gov when the
contract action is expected to exceed $25,000, unless an exception
under FAR 5.202 applies.
(d) Other than as identified in paragraphs (a) through (c) of this
section, the contracting officer need not publicize the proposed
acquisition of a leasehold interest in real property, including
expansion requests within the scope of a lease (see 570.403), lease
extensions under the conditions defined in 570.405, and building
alterations within the scope of a lease (see 570.5). However, the
contracting officer may publicize proposed lease acquisitions of any
dollar value or square footage in http://www.FBO.gov or local
newspapers if, in the opinion of the contracting officer, doing so is
necessary to promote competition.
(e) The contracting officer may issue a consolidated advertisement
for multiple leasing actions.
(f) Except as otherwise provided in paragraph (b) of this section,
where publicizing of the proposed acquisition is required, the notice
shall be published in http://www.FBO.gov not less than three calendar
days prior to issuance of a solicitation.
(g) Except as otherwise provided in paragraph (b) of this section
and as set forth in paragraphs (g) and (h) of this section, the
contracting officer shall provide offerors not less than 20 calendar
days between solicitation issuance and the date established for receipt
of initial offers.
(1) For a proposed acquisition using simplified lease acquisition
procedures (see 570.2), consider the individual acquisition and
establish a reasonable response time.
(2) In cases of unusual and compelling urgency (FAR 6.303-2),
provide as much time as reasonably possible under the circumstances and
document the contract file.
(h) If a Member of Congress has specifically requested notification
of award, the contracting officer must provide award notifications in
accordance with 505.303.
0
27b. Add section 570.106-1 to read as follows:
570.106-1 Synopsis of lease awards.
(a) Except for lease actions described in paragraph (b) of this
section, contracting officers must synopsize in http://www.FBO.gov
awards exceeding $25,000 total contract value that are likely to result
in the award of any subcontracts. However, the dollar threshold is not
a prohibition against publicizing an award of a smaller amount when
publicizing would be advantageous to industry or to the Government.
(b) A notice is not required if--
(1) The notice would disclose the occupant agency's needs and the
disclosure of such needs would compromise the national security; or
(2) The lease--
(i) Is for an amount not greater than the simplified lease
acquisition threshold;
(ii) Was made through a means where access to the notice of
proposed lease action was provided through http://www.FBO.gov; and
(iii) Permitted the public to respond to the solicitation
electronically.
(c) Justifications for other than full and open competition must be
posted in http://www.FBO.gov. Information exempt from public disclosure
must be redacted.
570.107 [Amended]
0
28. Amend section 570.107 by removing ``You may use'' and adding ``The
contracting officer may require'' in its place.
570.108 [Amended]
0
29. Amend section 570.108 by--
0
a. Removing from paragraph (a) ``List of Parties Excluded from Federal
Procurement and Nonprocurement Programs'' and adding ``Excluded Parties
List System (EPLS)'' in its place;
0
b. Removing from paragraph (b) ``Your'' and adding ``The contracting
officer's'' in its place;
0
c. Removing from paragraph (c) ``you find'' and adding ``the
contracting officer finds'' in its place; and
0
d. Removing from paragraph (d) ``you find'' and adding ``the
contracting officer finds'' in its place.
570.109 [Amended]
0
30. Amend section 570.109 by removing from the introductory text
[[Page 30850]]
``certifications'' and adding ``representations and certifications'' in
its place.
0
31. Amend section 570.110 by revising paragraph (b) to read as follows:
570.110 Cost or pricing data and information other than cost or
pricing data.
* * * * *
(b) FAR 15.403-1 defines exceptions to and waivers for submitting
cost or pricing data. Most leasing actions will have adequate price
competition. For price analysis of offered rental rates, the
contracting officer may use a market survey, an appraisal conducted
using accepted real property appraisal procedures to establish a market
price for comparison, or other relevant market research data. For price
analysis of offered tenant improvement costs, obtain two offers or cost
and pricing data.
* * * * *
0
32. Revise section 570.111 to read as follows:
570.111 Inspection and acceptance.
Before accepting the space, the contracting officer must verify
that the space complies with the Government's requirements and
specifications and document this in an inspection report. The
inspection and acceptance document must contain the square footage
accepted and the acceptance date. Include the inspection and acceptance
in the contract file. When space such as piers, antennas, and parking
are leased, square footage may not be the manner in which the amount of
space is specified; therefore, document that the space complies with
the Government's written requirements.
570.112 [Amended]
0
33. Amend section 570.112 by removing ``you receive'' and adding ``the
contracting officer receives'' in its place.
0
34. Revise section 570.113 to read as follows:
570.113 Disclosure of mistakes after award.
If a mistake in a lessor's offer is discovered after award, the
contracting officer should process it substantially in accordance with
FAR 14.407-4 and GSAM 514.407-4.
0
35. Add sections 570.115, 570.116, 570.117, 570.117-1, and 570.117-2 to
read as follows:
570.115 Novation and change of ownership.
In the event of a transfer of ownership of the leased premises or a
change in the lessor's legal name, FAR 42.12 applies.
570.116 Contract format.
The uniform contract format is not required for leases of real
property.
570.117 Sustainable requirements for lease acquisition.
Contracting officers must include sustainable design requirements
appropriate for the type of leasing action in the solicitations for
offers. Contracting officers can find solicitation requirements and
instructions on http://www.gsa.gov/leasing under Leasing Policies and
Procedures, Green Leasing, and in the Leasing Desk Guide to assist them
in complying with GSA's sustainable requirements identified in this
part.
570.117-1 Federal leadership in environmental, energy, and economic
performance.
In order to create a clean energy economy that will increase our
Nation's prosperity, promote energy security, protect the interests of
taxpayers, and safeguard the health of our environment, GSA will
accomplish all requirements of E.O. 13514 that apply to lease
acquisition.
570.117-2 Guiding principles for federal leadership in high
performance and sustainable buildings.
GSA is committed to the design, construction, operation, and
maintenance of leased space that comply with all of the following
Guiding Principles:
(a) Employ Integrated Design Principles;
(b) Optimize Energy Performance;
(c) Protect and Conserve Water;
(d) Enhance Indoor Environmental Quality; and
(e) Reduce the Environmental Impact of Building Materials.
0
36. Amend section 570.203-2 by--
0
a. Revising paragraph (a); and
0
b. Removing from paragraph (b) ``you solicit'' and adding ``the
contracting officer solicits'' in its place.
The revised text reads as follows:
570.203-2 Competition.
(a) To the maximum extent practicable, the contracting officer must
solicit at least three sources to promote competition. If there are
repeated requirements for space in the same market, invite two sources,
if practicable, that are not included in the most recent solicitation
to submit offers.
* * * * *
0
37. Revise section 570.203-3 to read as follows:
570.203-3 Soliciting offers.
(a) The contracting officer must solicit offers by providing each
prospective offeror a proposed short form lease GSA Form 3626 or SFO.
The short form lease or SFO must:
(1) Describe the Government's requirements.
(2) List all award factors, including price or cost, and any
significant subfactors that the contracting officer will consider in
awarding the lease.
(3) State the relative importance of the evaluation factors and
subfactors.
(4) State whether all evaluation factors other than cost or price,
when combined, are either:
(i) Significantly more important than cost or price.
(ii) Approximately equal in importance to cost or price.
(iii) Significantly less important than cost or price.
(5) Include either in full text or by reference, applicable FAR
provisions and contract clauses required by 570.6.
(6) Include sustainable design requirements.
(b) As necessary, review with prospective offerors the Government's
requirements, pricing matters, evaluation procedures and submission of
offers.
0
38. Revise section 570.203-4 to read as follows:
570.203-4 Negotiation, evaluation, and award.
(a) If the contracting officer needs to conduct negotiations, use
the procedures in 570.307.
(b) Evaluate offers in accordance with the solicitation. Evaluate
prices and document the lease file to demonstrate whether the proposed
contract prices are fair and reasonable. See 570.110.
(c) If the total price, including options, exceeds the amount
established by FAR 15.403-4, consider whether the contracting officer
needs cost and pricing data to determine that the price is fair and
reasonable. In most cases, the exceptions at FAR 15.403-1 will apply.
(d) Regardless of the process used, the contracting officer must
determine whether the price is fair and reasonable.
(e) If the total contract value of the lease, including options,
will exceed the amount established by FAR 19.702(a), the proposed
awardee must provide an acceptable small business subcontracting plan.
This requirement does not apply if the proposed awardee is a small
business concern.
(f) Make award to the responsible offeror whose proposal represents
the best value to the Government considering price and other factors
included in the solicitation.
[[Page 30851]]
Subpart 570.3--Acquisition Procedures for Leasehold Interests in
Real Property Over the Simplified Lease Acquisition Threshold
0
39. Revise the heading of subpart 570.3 to read as set forth above.
0
40. Amend section 570.303-1 by removing from the introductory text
``provide all the following'', removing from paragraph (h) ``570.7''
and adding ``570.8'' in its place, and adding a new paragraph (i) to
read as follows:
570.303-1 Preparing the SFO.
* * * * *
(i) Include sustainable design requirements.
0
41. Revise section 570.303-2 to read as follows:
570.303-2 Issuing the SFO.
Release the SFO to all prospective offerors at the same time. The
SFO may be released electronically.
0
42. Amend section 570.303-4 by revising paragraph (d) and adding
paragraph (e) to read as follows:
570.303-4 Changes to SFOs.
* * * * *
(d) If an amendment is so substantial that it requires a complete
revision of the SFO, cancel the SFO, readvertise if required by
570.106, and issue a new SFO.
(e) If there are changes to the Government's requirements for
amount of space, delineated area, occupancy date, and/or other major
aspects of the requirements, the contracting officer shall consider
whether there is a need to readvertise, and to document the file
accordingly.
0
43. Amend section 570.304 by revising the introductory text of
paragraph (a), and revising paragraphs (c) and (d), to read as follows:
570.304 General source selection procedures.
(a) These procedures apply to acquisitions of leasehold interests
except if the contracting officer uses one of the following:
* * * * *
(c) In a trade off procurement, the contracting officer must
include price or cost to the Government, past performance, the planned
participation of small disadvantaged business concerns in performance
of the contract, and other factors as required by FAR 15.304 as
evaluation factors. The contracting officer may include other
evaluation factors as needed.
(d) The evaluation factors and significant subfactors must comply
with FAR 15.304 and either one of the following:
(1) FAR 15.101-1 if the contracting officer will use the tradeoff
process.
(2) FAR 15.101-2 if the contracting officer will use the lowest
price technically acceptable source selection process.
0
44. Amend section 570.305 by--
0
a. Removing from paragraph (a) ``you use'' and adding ``the contracting
officer uses'' in its place, and adding ``Follow FAR 36.3.'' to the end
of the paragraph;
0
b. Redesignating paragraph (c)(1)(iv) as paragraph (c)(1)(v), and
adding a new paragraph (c)(1)(iv); and
0
c. Revising paragraphs (c)(2) and introductory text of paragraph (d).
The revised and added text reads as follows:
570.305 Two-phase design-build selection procedures.
* * * * *
(c) * * *
(1) * * *
(iv) The planned participation of small disadvantaged business
concerns in performance of the contract.
* * * * *
(2) The contracting officer shall not require offerors to submit
detailed design information or cost or price information in phase one.
The contracting officer shall not use cost related or price related
evaluation factors.
(d) The contracting officer shall set the maximum number of
offerors to be selected for phase-two to not exceed five unless the
contracting officer determines that a number greater than five is both:
* * * * *
0
45. Amend section 570.306 by--
0
a. Removing from paragraph (a) ``You'' and adding ``The contracting
officer'' in its place;
0
b. Revising paragraphs (b) and (c);
0
c. Redesignating paragraph (d) as paragraph (e), and adding a new
paragraph (d); and
0
d. Adding paragraph (f).
The revised and added text reads as follows:
570.306 Evaluating offers.
* * * * *
(b) Evaluate prices and document the lease file to demonstrate that
the proposed contract price is fair and reasonable. The contracting
officer must review the elements of the offeror's proposed rent to
analyze whether the individual elements are realistic and reflect the
offeror's clear understanding of the work to be performed. The
contracting officer must discuss any inconsistencies with the offeror.
If the offeror refuses to support or make any changes to the rent
proposed, consider the risk to the Government prior to making any lease
award.
(c) Evaluate past performance on previous lease projects in
accordance with 515.305 and FAR 15.305(a)(2). Obtain information
through:
(1) Questionnaires tailored to the circumstances of the
acquisition;
(2) Interviews with program managers or contracting officers;
(3) Other sources; or
(4) Past performance information collected under FAR 42.15 and
available through the Past Performance Information Retrieval System
(PPIRS) at http://www.ppirs.gov.
(d) The contracting officer may obtain information to evaluate an
offeror's past performance on subcontracting plan goals and small
disadvantaged business participation, monetary targets, and
notifications under FAR 19.1202-4(b) from the following sources:
(1) The Small Business Administration;
(2) Information on prior contracts from contracting officers and
administrative contracting officers;
(3) Offeror's references; and
(4) Past performance information collected under FAR 42.15 and
available through PPIRS.
* * * * *
(f) Also see the requirements in 570.108, 570.109 and 570.111.
0
46. Revise section 570.308 to read as follows:
570.308 Award.
(a) Make award to the responsible offeror whose proposal represents
the best value after evaluation in accordance with the factors and
subfactors in the SFO.
(b) Make award in writing and in the timeframe specified in the
SFO.
(1) If the contracting officer cannot make an award in that time,
request in writing from each offeror an extension of the acceptance
period through a specific date.
(2) If time is critical, the contracting officer may request the
extensions orally. The contracting officer must make a record of the
request and confirm it promptly in writing.
(c) Notify unsuccessful offerors in writing or electronically in
accordance with FAR 15.501 and 15.503(b).
(d) The source selection authority may reject all proposals
received in response to an SFO, if doing so is in the best interest of
the Government.
0
47. Revise section 570.401 to read as follows:
[[Page 30852]]
570.401 Renewal options.
(a) Exercise of options. Before exercising an option to renew,
follow the procedures in 517.207. The contract must first provide the
right to renew the lease. If a renewal option was not evaluated as part
of the lease at award, then the addition of a renewal option during the
lease term must satisfy the requirements of GSAM 506 regarding full and
open competition.
(b) Market information review. Before exercising an option to renew
a lease, review current market information to determine that the rental
rate in the option is fair and reasonable.
0
48. Revise section 570.402-1 to read as follows:
570.402-1 General.
(a) If a succeeding lease for the continued occupancy of space in a
building does not exceed the simplified lease acquisition threshold,
the contracting officer may use the simplified procedures in 570.2.
Explain the absence of competition in the contract file.
(b) If a succeeding lease will exceed the simplified lease
acquisition threshold, the contracting officer may enter into the lease
under either of the following conditions:
(1) The contracting officer does not identify any potential
acceptable locations.
(2) The contracting officer identifies potential acceptable
locations, but a cost-benefit analysis indicates that award to an
offeror other than the present lessor will result in substantial
relocation costs or duplication of costs to the Government, and the
Government cannot expect to recover such costs through competition.
0
49. Amend section 570.402-2 by revising the introductory text, and
paragraphs (a) through (c) to read as follows:
570.402-2 Publicizing/Advertising.
The contracting officer must publish a notice if required by
570.106. The notice should:
(a) Indicate that the Government's lease is expiring.
(b) Describe the requirements in terms of type and quantity of
space.
(c) Indicate that the Government is interested in considering
alternative space if economically advantageous, and that otherwise the
Government intends to pursue a sole source acquisition.
* * * * *
0
50. Amend section 570.402-4 by removing ``you do'' and adding ``the
contracting officer does'' in its place, and removing ``you may prepare
a'' and adding ``prepare a written'' in its place.
570.402-5 [Amended]
0
51. Amend section 570.402-5 by removing from the introductory text
``you identify'' and adding ``the contracting officer identifies'' in
its place, and removing from paragraph (b)(1) ``you'' and adding ``the
contracting officer'' in its place.
570.403 [Amended]
0
52. Amend section 570.403 by--
0
a. Removing from paragraph (a) ``you'' and adding ``the contracting
officer'' in its place;
0
b. Removing from the introductory text of paragraph (b) ``determine''
and adding ``the contracting officer must determine'' in its place, and
removing ``or to satisfy'' and adding ``or to meet the expansion
requirement and existing tenancy to'' in its place;
0
c. Removing from the introductory text of paragraph (c) ``you
determine'' and adding ``the contracting officer determines'' in its
place.
570.404 [Amended]
0
53. Amend section 570.404 by removing from paragraph (a), ``.'' and
adding ``or when market conditions warrant renegotiation of an existing
lease.'' in its place; and removing from paragraph (b) ``you'' and
adding ``the contracting officer'' in its place.
0
54. Amend section 570.405 by--
0
a. Removing from paragraph (b) ``you'' and adding ``the contracting
officer'' in its place;
0
b. Removing from the introductory text of paragraph (c) ``such as the''
and adding ``such as, but not limited to, the'' in its place;
0
c. Removing from paragraph (c)(3) ``agencies occupying the leased space
and you need'' and adding ``agencies and the contracting officer
needs'' in its place; and
0
d. Adding paragraph (c)(4).
The added text reads as follows:
570.405 Lease extensions.
* * * * *
(c) * * *
(4) The agency occupying the space has encountered delays in
planning for a potential relocation to other federally controlled space
due to documented organizational, financial, or other uncertainties.
0
55. Amend section 570.501 by--
0
a. Revising the introductory text of paragraph (a), and paragraph
(a)(1);
0
b. Removing from the introductory text of paragraph (b) ``general'';
and
0
c. Removing from paragraph (b)(1) ``justified'' and adding ``as
justified'' in its place.
The revised text reads as follows:
570.501 General.
(a) The procedures in 570.502 apply to alterations acquired
directly from a lessor by modification or supplemental lease agreement.
This is allowed if the following conditions are met:
(1) The alterations fall within the scope of the lease. Consider
whether the work can be regarded fairly and reasonably as part of the
original lease requirement.
* * * * *
0
56. Revise sections 570.502, 570.502-1, and 570.502-2 to read as
follows:
570.502 Alterations by the lessor.
570.502-1 Justification and approval requirements.
If the proposed alterations are outside the general scope of the
lease and the contracting officer plans to acquire them from the lessor
without competition, the following justification and approval
requirements apply:
(a) If the alteration project will not exceed the micro-purchase
threshold identified in FAR 2.101(b), no justification and approval is
required.
(b) If the alteration project will exceed the micro-purchase
threshold identified in FAR 2.101(b), but not the simplified lease
acquisition threshold, the contracting officer may use simplified
acquisition procedures and explain the absence of competition in the
file.
(c) If the alteration project will exceed the simplified lease
acquisition threshold, the justification and approval requirements in
FAR 6.3 and 506.3 apply.
570.502-2 Procedures.
(a) Scope of work. The contracting officer must prepare a scope of
work for each alteration project.
(b) Independent Government estimate. The contracting officer must
obtain an independent Government estimate for each alteration project,
including changes to existing alteration agreements with the lessor.
(c) Request for proposal.
(1) The contracting officer must provide the scope of work to the
lessor, including any plans and specifications, and request a proposal.
(2) The contracting officer must request sufficient cost or price
information to permit a price analysis.
(d) Audits. If the contracting officer requires cost or pricing
data and the alteration project will exceed the threshold identified in
FAR 15.403-4, request an audit.
[[Page 30853]]
(e) Proposal evaluation. The contracting officer must--
(1) Determine if the proposal meets the Government's requirements.
(2) Analyze price or cost information. At a minimum, compare the
proposed cost to the independent estimate and, if applicable, any audit
results received.
(3) Analyze profit following FAR 15.404-4.
(4) Document the analysis under this paragraph and the resulting
negotiation objectives.
(f) Price negotiations. The contracting officer must--
(1) Exercise sound judgment. Make reasonable compromises as
necessary.
(2) Provide the lessor with the greatest incentive for efficient
and economical performance.
(3) Document negotiations in the contract file, including
discussions regarding restoration cost or waiver of restoration cost.
(g) Order. For modifications not exceeding the simplified
acquisition threshold, lease contracting officers may delegate
alteration contracting authority to a warranted contracting officer's
representative in GSA or the tenant agency. Alterations awards must
reference the lease number. If the modification does not exceed the
simplified acquisition threshold, the contracting officer may use GSA
Form 300, Order for Supplies or Services. Reference the lease on the
form.
(h) Inspection and payment. The contracting officer must not make
final payment for alterations until the work is:
(1) Inspected by a qualified Government employee or independent
Government contractor.
(2) Confirmed as completed in a satisfactory manner.
0
57. Revise section 570.503 to read as follows:
570.503 Alterations by the Government or through a separate contract.
If the Government chooses to exercise its right to make the
alterations rather than contracting directly with the lessor, the
Government may either:
(a) Have Federal employees perform the work.
(b) Contract out the work using standard contracting procedures
that apply to a construction contract performed on Federal property. If
the Government decides to contract for the work, invite the lessor, as
well as all other prospective contractors, to submit offers for the
project.
0
58a. Redesignate Subparts 570.6 (consisting of 570.601 through 570.604)
and 570.7 (consisting of 570.701 through 570.702) as Subparts 570.7
(consisting of 570.701 through 570.704) and 570.8 (consisting of
570.801 through 570.802), respectively;
0
58b. Add a new Subpart 570.6 to read as follows:
Subpart 570.6--Contracting for Overtime Services and Utilities in
Leases
Sec.
570.601 General.
Subpart 570.6--Contracting for Overtime Services and Utilities in
Leases
570.601 General.
(a) Lease tenant agencies may need overtime services and utilities
on a regular or intermittent basis. Lease contracting officers may
negotiate overtime rates for services and utilities and include those
rates in leases where a need is projected. Only lease contracting
officers may negotiate overtime rates.
(b) An independent government estimate is required in support of
the negotiated rate.
(c) Order. To order overtime services and utilities, if the order
does not exceed the simplified acquisition threshold, a warranted
contracting officer's representative, in GSA or the tenant agency, may
place an order. The order must reference the lease number.
(d) Payment. Do not make final payment for services and utilities
until confirmed as delivered in a satisfactory manner.
0
59. Revise the newly redesignated section 570.701 to read as follows:
570.701 FAR provisions and clauses.
Include provisions or clauses substantially the same as the FAR
provisions and clauses listed below.
------------------------------------------------------------------------
If . . . Then include . . .
------------------------------------------------------------------------
(a) the estimated value of the 52.204-3 Taxpayer
acquisition exceeds the micro-purchase Identification.
threshold identified in FAR 2.101. 52.204-6 Data Universal
Numbering System (DUNS)
Number.
52.204-7 Central Contractor
Registration.
52.219-1 Small Business Program
Representations.
52.219-28 Post-Award Small
Business Program
Rerepresentation (use if lease
term exceeds five years).
52.232-23 Assignment of Claims.
52.232-33 Electronic Funds
Transfer--Central Contractor
Registration.
52.233-1 Disputes.
(b) the estimated value of the 52.222-21 Prohibition of
acquisition exceeds $10,000. Segregated Facilities.
52.222-22 Previous Contracts
and Compliance Reports.
52.222-25 Affirmative Action
Compliance.
52.222-26 Equal Opportunity.
52.222-35 Affirmative Action
for Disabled Veterans and
Veterans of the Vietnam Era.
52.222-36 Affirmative Action
for Workers with Disabilities.
52.222-37 Employment Reports on
Disabled Veterans and Veterans
of the Vietnam Era.
(c) the estimated value of the 52.204-10 Reporting Executive
acquisition is $25,000 or more (not Compensation and First-Tier
applicable to individuals). Subcontract Awards.
(d) the estimated value of the 52.209-6 Protecting the
acquisition exceeds the threshold Government's Interest when
identified in FAR 9.409(b). Subcontracting with
Contractors Debarred,
Suspended, or Proposed for
Debarment.
(e) the estimated value of the 52.203-11 Certification and
acquisition exceeds $100,000. Disclosure Regarding Payments
to Influence Certain Federal
Transactions.
(f) the estimated value of the 52.203-2 Certificate of
acquisition exceeds the simplified Independent Price
lease acquisition threshold. Determination.
52.203-7 Anti-Kickback
Procedures.
52.204-5 Women-Owned Business
(Other than Small Business).
52.209-5 Certification
Regarding Debarment,
Suspension, Proposed
Debarment, and Other
Responsibility Matters.
[[Page 30854]]
52.215-2 Audit and Records--
Negotiation.
52.219-8 Utilization of Small
Business Concerns.
52.223-6 Drug-Free Workplace.
52.233-2 Service of Protest.
(g) the estimated value of the 52.219-9 Small Business
acquisition exceeds the threshold Subcontracting Plan.
identified in FAR 19.708(b). 52.219-16 Liquidated Damages--
Subcontracting Plan.
(h) the estimated value of the 52.219-24 Small Disadvantaged
acquisition the estimated value of the Business Participation
acquisition exceeds the threshold Program--Targets.
identified in FAR 19.1202-2(a) and the 52.219-25 Small Disadvantaged
contracting officer is using a best Business Participation
value trade off analysis in an Program--Disadvantaged Status
acquisition includes an evaluation and Reporting.
factor that considers the extent of
participation of small disadvantaged
business concerns in accordance with
FAR 19.12.
(i) the value of the contract is 52.203-13 Contractor Code of
expected to exceed $5 million and the Business Ethics and Conduct.
performance period is 120 days or more. 52.203-14 Display of Hotline
Poster(s).
(j) the estimated value of the 52.222-24 Pre-award On-site
acquisition exceeds $10 million. Equal Opportunity Compliance
Review.
(k) the contracting officer requires 52.215-10 Price Reduction for
cost or pricing data for work or Defective Cost or Pricing Data
services exceeding the threshold 52.215-12 Subcontractor Cost or
identified in FAR 15.403-4. Pricing Data.
(l) the contracting officer authorizes 52.215-5 Facsimile Proposals.
submission of facsimile proposals.
(m) a negotiated acquisition provides 52.219-26 Small Disadvantaged
monetary incentives based on actual Business Participation
achievement of small disadvantaged Program--Incentive
business subcontracting targets under Subcontracting.
FAR 19.1203 and 519.1203.
------------------------------------------------------------------------
570.702 [Amended]
0
60. Revise the introductory text of the newly designated section
570.702 to read as follows:
570.702 GSAR Solicitation provisions.
Each SFO must include provisions substantially the same as the
following, unless the contracting officer determines that the provision
is not appropriate. However, document the file with the basis for
deleting or substantially changing a clause.
* * * * *
0
61. Revise the newly redesignated section 570.703 to read as follows:
570.703 GSAR contract clauses.
(a) Insert clauses substantially the same as the following in
solicitations and contracts for leasehold interests in real property
that exceed the simplified lease acquisition threshold, unless the
contracting officer determines that a clause is not appropriate.
However, document the file with the basis for deleting or substantially
changing a clause. A deviation is not required under section 570.704 to
determine that a clause in this section is not appropriate. Use the
clauses at your discretion in actions at or below the simplified lease
acquisition threshold.
552.215-70 Examination of Records by GSA.
552.270-4 Definitions. You must use this clause if you use 552.270-28.
552.270-5 Subletting and Assignment.
552.270-6 Maintenance of Building and Premises--Right of Entry.
552.270-7 Fire and Casualty Damage.
552.270-8 Compliance with Applicable Law.
552.270-9 Inspection--Right of Entry.
552.270-10 Failure in Performance.
552.270-11 Successors Bound.
552.270-12 Alterations.
552.270-13 Proposals for Adjustment.
552.270-14 Changes.
552.270-15 Liquidated Damages. Insert this clause in solicitations and
contracts if you have a critical requirement to meet the delivery date
and you cannot establish an actual cost for the loss to the Government
resulting from late delivery.
552.270-16 Adjustment for Vacant Premises.
552.270-17 Delivery and Condition.
552.270-18 Default in Delivery--Time Extensions.
552.270-19 Progressive Occupancy.
552.270-20 Payment.
552.270-21 Effect of Acceptance and Occupancy.
552.270-22 Default by Lessor During the Term.
552.270-23 Subordination, Nondisturbance and Attornment
552.270-24 Statement of Lease.
552.270-25 Substitution of Tenant Agency.
552.270-26 No Waiver.
552.270-27 Integrated Agreement.
552.270-28 Mutuality of Obligation.
552.270-29 Acceptance of Space.
(b) Include the following provisions and clauses in leasehold
interests in real property.
552.270-30 Price Adjustment for Illegal Improper Activity.
552.270-31 Prompt Payment.
552.270-32 Covenant Against Contingent Fees.
0
62. Revise section 570.704 to read as follows:
570.704 Deviations to provisions and clauses.
(a) The contracting officer needs a deviation approved under
Subpart 501.4 to omit any required provision or clause.
(b) The contracting officer also needs an approved deviation to
modify the language of a provision or clause mandated by statute (e.g.,
FAR 52.215-2, Audit and Records--Negotiation). The authorizing statute
must allow for a waiver.
(c) Certain clauses required by non-GSA regulations require
approval of the issuing agency before the contracting officer can
delete or modify them. For example, FARs 52.222-26, Equal Opportunity;
52.222-35, Affirmative Action for Disabled Veterans and Veterans of the
Vietnam Era; and 52.222-36, Affirmative Action for Workers with
Disabilities, require the approval of the Department of Labor's Office
of Federal Contract Compliance Programs before they can be deleted from
or modified in the SFO or lease.
0
63. Revise the newly redesignated section 570.801 to read as follows:
570.801 Standard forms.
Use Standard Form 2, U.S. Government Lease for Real Property, to
award leases unless the contracting officer uses GSA Form 3626 (see
570.802).
0
64. Revise the newly redesignated section 570.802 to read as follows:
570.802 GSA Forms
(a) The contracting officer may use GSA Form 3626, U.S. Government
Lease for Real Property (Short Form), to award leases if using the
simplified leasing procedures in Subpart 570.2 or if the contracting
officer determines it advantageous to use the form.
(b) The contracting officer may use GSA Form 276, Supplemental
Lease
[[Page 30855]]
Agreement, for actions requiring the agreement of both parties. This
includes actions such as amending an existing lease to acquire
additional space, obtaining partial release of space, revising the
terms of a lease, settling restoration claims, and acquiring
alterations.
(c) The contracting officer may use GSA Form 1364, Proposal To
Lease Space to obtain offers from prospective offerors.
(d) The contracting officer may use GSA Form 1217, Lessor's Annual
Cost Statement, to obtain pricing information regarding offered
services and lease commissions.
[FR Doc. 2011-12198 Filed 5-26-11; 8:45 am]
BILLING CODE 6820-61-P