Federal Property and Administrative Services Act of 1949, as amended (40 U.S.C. 486 (c)), as delegated by the Secretary of Commerce in Department Organization Order 10-5 and Department Administrative Order 208-2.
This subpart states the relationship of the Commerce Acquisition Regulation (CAR) to the Federal Acquisition Regulation (FAR). This subpart also explains the purpose, authority and issuance of the CAR.
(a) Chapter 13 of Title 48 of the Code of Federal Regulations shall be known as the Commerce Acquisition Regulation (CAR).
(b) The purpose of the CAR is to implement and supplement the FAR within the Department of Commerce. Since the CAR is intended to supplement and implement the FAR without paraphrasing or duplicating FAR language, the CAR should be read in relation to the FAR.
The CAR is prescribed by the Department Procurement Executive pursuant to a delegation initiating from the Secretary of Commerce in accordance with the Federal Property and Administrative Services Act of 1949, as amended, and other applicable law and regulation.
The FAR and CAR apply to all acquisitions within the Department of Commerce.
(a) The CAR is published in (1) daily issues of the
(b) The CAR is issued as chapter 13 of title 48 of the CFR.
(a)
(b)
(c)
(3) References to FAR materials will include FAR and the identifying number, for example, FAR 1.402. Reference to CAR materials will consist of the identifying number, for example 1301.402.
(a) Copies of the CAR in
(b) Loose-leaf copies of the CAR are distributed within the Department by the Procurement Executive.
(a) The Department is not bound by any formal or informal type of agreement or contractual commitment which is made by persons who are not delegated contracting authority. When these unauthorized acts are discovered they shall be immediately reported to the Head of the Contracting Activity concerned. The Head of the Contracting Activity shall:
(1) Immediately inform any person who is performing work as a result of an unauthorized commitment that the work is being performed at that person's risk;
(2) Decide whether ratification of the unauthorized act is proper, and take appropriate action.
Federal Property and Administrative Services Act of 1949, as amended (40 U.S.C. 486(c)), as delegated by the Secretary of Commerce in Department Organization Order 10-5 and Department Administrative Order 208-2.
The agency rules implementing Executive Order 11222 are contained in the Department Administrative Order on
Suspected violations of the Gratuities clause shall be reported to the head of the contracting office in writing detailing the circumstances. The head of the contracting office will evaluate the report and if the allegations appear to support a violation the matter will be referred to the Office of Inspector General in accordance with the Department Administrative Order
(a) Executive Order 12430 revoked the requirement of Executive Order 10936 to submit a report to the Attorney General on identical bids.
(b) Suspected anti-competitive practices and antitrust law violations as described in FAR 3.301 and FAR 3.303 shall be reported to the general counsel through the Head of the Contracting Activity. A copy of the report shall be sent to the Procurement Executive concurrently with the submission to the general counsel.
Suspected violations of the Covenant Against Contingent Fees shall be reported to the Office of Inspector General in accordance with the Department Administrative Order on
Suspected violations of the Anti-Kickback Act shall be reported to the Office of Inspector General in accordance with the Department Administrative Order on
Federal Property and Administrative Services Act of 1949, as amended (40 U.S.C 486(c)), as delegated by the Secretary of Commerce in Department Organization Order 10-5 and Department Administrative Order 208-2.
(a)
(b)
(c)
(1) Acceptable facilities and equipment for special production techniques (e.g., unique welding procedures, special test fixtures, or production equipment);
(2) Adequate size and lift capacity for the drydock or marine railway;
(3) Well maintained drydock and lifting equipment and acceptable preventative maintenance of these items;
(4) Acceptable dock master and crew who are experienced in operating the equipment and lifting a vessel of comparable size and weight;
(5) Adequate drydock or pier utilities to support the vessel, including electrical power, steam, potable water, fire fighting capability, sewage disposal, and telephone service;
(6) Responsible subcontractors;
(7) Contractor's demonstrated ability to monitor and coordinate subcontractor performance;
(8) Contractor's demonstrated ability to conduct dock and sea trials;
(9) Contractor's demonstrated ability to protect the vessel and yard and vessel personnel, including safety and security programs or individual plans;
(10) Adequate secure storage facilities for Government property; and
(11) The depth of water in the navigable waterway and the pier where the vessel will be berthed.
(d)
(1) A cost or price analyst or cognizant audit agency for review of the contractor's financial and accounting systems;
(2) Technical or requirements personnel from the cognizant marine center or office of marine operations, for technical, production, or quality assurance evaluations; and
(3) Representatives of the contracting officer for management and administrative evaluations.
(e)
(f)
(1) The depth of water in the navigable waterway and the pier where the vessel will be berthed;
(2) The condition of the drydock or marine railway where the work is to be performed;
(3) Availability of adequate utilities and services for the vessel;
(4) Evidence of prospective contractor or subcontractor financial problems or poor past performance.
(g)
Federal Property and Administrative Services Act of 1949, as amended (40 U.S.C. 486(c)), as delegated by the Secretary of Commerce in Department Organization Order 10-5 and Department Administrative Order 208-2.
(a)
(b)
Federal Property and Administrative Services Act of 1949, as amended (40 U.S.C. 486(c)), as delegated by the Secretary of Commerce in Department Organization Order 10-5 and Department Administrative Order 208-2.
The procedures described in FAR 15.413-2 may be used if approved by the Head of the Contracting Activity or designee.
(a) When it appears that a person or firm is interested in making a proposal, that person or firm should be referred to the head of the contracting office concerned who will provide instructions for submission of an unsolicited proposal.
(b) Heads of contracting offices shall provide instructions for submission of unsolicited proposals to each person or firm which expresses an interest in submitting an unsolicited proposal.
(a) Promptly after receipt of an unsolicited proposal which conforms to this regulation, the head of the contracting
(b) Program offices receiving unsolicited proposals for evaluation shall conduct the evaluation in accordance with this subpart 1315.5, FAR Subpart 15.5, and any additional guidance provided by the Office of Procurement and Federal Assistance.
(c) Program offices shall complete the recommendation and evaluations and submit them along with all copies of the unsolicited proposal, and a written justification for a noncompetitive procurement action if appropriate, to the head of the appropriate contracting office within 60 days of receipt of a proposal for evaluation.
(d) No part of an unsolicited proposal shall be duplicated or circulated outside of the evaluation office. Each unsolicited proposal shall be closely safeguarded to prevent disclosure of any restricted data. Only heads of contracting offices or their designees may duplicate unsolicited proposals and then only to facilitate evaluation by more than one technical evaluation office.
(a) Preaward audits should not be routinely requested for actions below the dollar threshold specified in FAR 15.805-5. Before requesting audits below the dollar threshold, the contracting office should consider using price or cost analysis techniques, recent audit reports, price negotiation memoranda, and other relevant information regarding the offer to establish the reasonableness of price. However, audits should be considered for proposals below the specified dollar thresholds in the following circumstances:
(1) The contracting officer has reason to doubt the adequacy of the contractor's accounting policies or cost systems;
(2) The contractor has substantially changed its methods or levels of operation;
(3) Previous unfavorable experience indicates that the contractor's estimating, accounting, or purchasing methods may be unreliable; or
(4) The proposal concerns a new product for which cost experience is lacking.
(a) Except as provided in (b) and (c) of this section, a structured approach for determining profit or fee prenegotiation objectives shall be used in the negotiation of all contracts, subcontracts, and contract modifications above $100,000 where adequate price competition does not exist. A structured approach for determining profit or fee prenegotiation objectives may be used at lower dollar thresholds.
(b) Regardless of whether price competition exists, the structured approach for determining profit or fee prenegotiation objectives is not required for negotiation of contracts, subcontracts, and contract modifications for the following:
(1) Architect—engineering contracts;
(2) Management contracts for operation or maintenance of Government facilities;
(3) Construction contracts;
(4) Contracts primarily requiring delivery of material supplied by subcontractors;
(5) Termination settlements;
(6) Cost-plus-award-fee contracts; and
(7) Unusual pricing situations where the structured approach has been determined to be unsuitable. This exception must be justified in writing and signed by the head of the contracting office.
(c) In many circumstances, an examination of cost and profits is not required. Where adequate price competition exists and in other situations where cost analysis is not required
(d) Additional internal instruction on the use of the structured approach can be found in Procurement Letters or policy manuals issued by the Office of Procurement and Federal Assistance.
Federal Property and Administrative Services Act of 1949, as amended (40 U.S.C. 486(c)), as delegated by the Secretary of Commerce in Department Organization Order 10-5 and Department Administrative Order 208-2.
(d)
Federal Property and Administrative Services Act of 1949, as amended (40 U.S.C. 486(c)), as delegated by the Secretary of Commerce in Department Organization Order 10-5 and Department Administrative Order 208-2.
(a)(1) The contracting officer shall insert the following clauses in sealed bid fixed-price solicitations and contracts for ship construction, ship alteration, and ship repair.
(i) Inspection and Manner of Doing Work, 1352.217-90.
(ii) Delivery of the Vessel to the Contractor, 1352.217-91.
(iii) Performance, 1352.217-92.
(iv) Delays, 1352.217-93.
(v) Minimization of Delay Due to Government Furnished Property, 1352.217-94.
(vi) Additional Provisions Relating to Government Property, 1352.217-95.
(vii) Liability and Insurance, 1352.217-96.
(viii) Title, 1352.217-97.
(ix) Discharge of Liens, 1352.217-98.
(x) Department of Labor Occupational Safety and Health Standards for Ship Repairing, 1352.217-99.
(xi) Regulations Governing Asbestos Work, 1352.217-100.
(xii) Complete and Final Equitable Adjustments, 1352.217-101.
(xiii) Government Review, Comment, Acceptance, and Approval, 1352.217-102.
(xiv) Access to the Vessel, 1352.217-103.
(xv) Documentation of Requests for Equitable Adjustment, 1352.217-104.
(xvi) Change Proposals, 1352.217-105.
(xvii) Lay Days, 1352.217-106.
(xviii) Changes—Ship Repair, 1352.217-107.
(xix) Default—Ship Repair, 1352.217-108.
(2) Unless inappropriate due to contract type, the contracting officer shall insert the clauses listed above in negotiated solicitations and contracts for ship construction, ship alteration, and ship repair.
(b) The contracting officer shall insert a clause substantially the same as the clause at 1352.217-109, Insurance Requirements, in solicitations and contracts for ship construction, ship alteration, and ship repair, unless the contracting officer determines that the contract, or job order, requires work on parts of a vessel only and the work is to be performed at a plant other than the site of the vessel.
(c) The contracting officer shall insert the clause at 1352.217-110, Guarantees, unless the contracting officer determines that its use would be inappropriate under the circumstances.
(d) The contracting officer shall insert the clause at 1352.217-111, Temporary Services, in solicitations and contracts for ship construction, ship alteration, and ship repair, unless the contracting officer determines that its use would be inappropriate under the circumstances.
(e) The contracting officer shall insert the provision at 1352.217-112, Self-Insurance Information, in solicitations and contracts for ship construction, ship alteration, and ship repair, when the contracting officer determines that it is appropriate to allow offerors the opportunity to self-insure for any or all of the risks set forth in the applicable insurance clauses of the contract.
Federal Property and Administrative Services Act of 1949, as amended (40 U.S.C. 486(c)), as delegated by the Secretary of Commerce in Department Organization Order 10-5 and Department Administrative Order 208-2.
(b) The contracting officer shall send a copy of the requisition form for all procurement actions expected to exceed $500,000 ($1,000,000 for construction) to the Office of Small and Disadvantaged Business Utilization, as promptly after receipt as possible. The Office of Small and Disadvantaged Business Utilization shall review the procurement actions and recommend action to the contracting officer. Orders under GSA schedule contracts, orders under Department or Government-wide indefinite delivery contracts, or actions within the scope of the changes, value engineering, or similar contract clauses are exempt from the requirements of this subsection.
(a) The contracting officer shall include women-owned small businesses on the mailing list for each solicitation which is expected to result in an award in excess of the small purchase dollar threshold whenever there are women-owned small businesses known to be potential suppliers.
(a) Contracting officers shall provide assistance to prime contractors to identify potential women-owned small businesses. Such assistance is intended to aid prime contractors in placing a fair proportion of subcontracts with women-owned small businesses.
(b) The contracting officer shall insert the clause at 1352.219-1, Women-Owned Small Business Sources, in solicitations and contracts where the clause prescribed by FAR 19.708(b) is required (see FAR 52.219-9).
Federal Property and Administrative Services Act of 1949, as amended (40 U.S.C. 486(c)), as delegated by the Secretary of Commerce in Department Organization Order 10-5 and Department Administrative Order 208-2.
(e)(2) Progress payments based on a percentage or stage of completion are authorized for use as a payment method under Department contracts and subcontracts for construction, alteration, repair, ship construction, ship alteration, and ship repair. For all other contracts, progress payments shall be based on costs except when the head of the contracting office determines that progress payments based on costs cannot be practically employed. In those cases, progress payments based on a percentage or stage of completion may be authorized when the head of the contracting office also determines that adequate safeguards are provided for the administration of those payments.
Federal Property and Administrative Services Act of 1949, as amended (40 U.S.C. 486(c)), as delegated by the Secretary of Commerce in Department Organization Order 10-5 and Department Administrative Order 208-2.
(a) Protests must be received within ten work days after the basis for protest is known or should have been known unless good cause is shown to extend the time limit. However, protests based upon alleged improprieties in any type of solicitation which are apparent prior to bid opening or the closing time for receipt of initial proposals shall be filed prior to bid opening or the closing time for receipt of initial proposals. Unless the time limit for receiving the protest is extended for good cause, a protest to the contracting activity which is received after the time limit will not be considered. When a timely protest is filed only with the contracting activity, the contracting
(b) When a protest is filed only with the contracting activity before award, an award shall not be made until the matter is resolved unless the head of the contracting office makes the determination prescribed in FAR 33.103(a).
(c) When a protest is filed only with the contracting activity after award, the contracting officer need not notify the contractor if the protest can be promptly resolved. If it appears likely that the award may be invalidated or that a protest will be filed with the GAO or the GSBCA, the contracting officer should promptly notify the contractor in writing and consider suspending contract performance.
(a)(1)
(2) The GAO report shall be assembled and organized by the contracting office in accordance with rule 4(d) of the GSBCA Rules of Procedure (48 CFR part 6101) except where rule 4(d) may conflict with GAO procedures.
(b)
(c)
(a)(1) A protestor shall furnish a copy of its complete protest to the contracting officer designated in the solicitation and a copy of its complete protest to the Contract Law Division of the Office of the Assistant General Counsel for Finance and Litigation, on the same day the protest is filed with the GSBCA. The envelope containing the complete protest shall be clearly marked “GSBCA Protest”.
(a) The contracting officer shall insert the provision at 1352.233-2, Service of Protest (JAN 1985) (Deviation FAR 52.233-2), in lieu of the provision at FAR 52.233-2 in solicitations for other than small purchases.
(a) The contracting officer may use Alternate I to the clause at FAR 52.233-1, Disputes, only after the Head of the Contracting Activity has determined in writing that—
(1) Continued performance is necessary pending resolution of any claim arising under or relating to the contract because of unusual circumstances
(2) Financing is or will be available for the continued performance; and
(3) The Government's interest is or will be properly secured.
The General Services Administration (GSA) Board of Contract Appeals serves as the Board of Contract Appeals for the Department.
Federal Property and Administrative Services Act of 1949, as amended (40 U.S.C. 486(c)), as delegated by the Secretary of Commerce in Department Organization Order 10-5 and Department Administrative Order 208-2.
The head of the contracting office is delegated the authority to approve the exceptional circumstance of awarding a contract for construction of a project to the firm that designed the project. Any approval of this type of award must be justified in writing and signed by the head of the contracting office.
Both short selection processes prescribed in FAR 36.602-5 may be used for contracts not to exceed $10,000. However, in either case the contracting officer shall review the report, approve it and commence negotiations or return it for appropriate revision.
Federal Property and Administrative Services Act of 1949, as amended (40 U.S.C. 486(c)), as delegated by the Secretary of Commerce in Department Organization Order 10-5 and Department Administrative Order 208-2.
(a) Generally, the final invoice shall not be approved until a close-out audit has been performed and all outstanding issues have been negotiated or resolved on the following types of contracts of $100,000 and above:
(1) Cost-reimbursement type contracts;
(2) The cost-reimbursement portion of fixed-price contracts;
(3) Letter contracts which provide for reimbursement of costs;
(4) Time and materials contracts; and
(5) Labor-hour contracts.
(b) Even though the $100,000 postaward audit threshold generally applies, an audit may be requested regardless of the dollar amount when the contracting officer determines that an audit is justified under one of the following circumstances:
(1) There is some evidence of fraud or waste;
(2) The contractor's performance under the contract has been questionable;
(3) The contractor had a high incidence of unallowable costs under a previous contract;
(4) The contract is with a newly established firm, or a firm which has just begun dealing with the Government.
Federal Property and Administrative Services Act of 1949, as amended (40 U.S.C. 486(c)), as delegated by the Sec'y of Commerce in Dept. Org. Order 10-5 and Dept. Adm. Order 208-2.
(a)
(1) Salaries and fringe benefits paid to Government employees who are assigned to a work activity (e.g., reprocurement activities) as a result of the default;
(2) Preaward survey expenses incurred in qualifying reprocurement contractors; and
(3) Costs incurred in printing and distributing the reprocurement solicitation.
(b)
(a) The contracting officer may recover administrative costs under the default clause when it is in the best interest of the Government. A contracting officer's decision to recover administrative costs must balance the expected cost to the Government of documenting and supporting the assessment with the expected recovery amount.
(b) Documents used to support an assessment of administrative costs must clearly demonstrate that the added costs incurred by the Government were a direct result of the default.
(1) To support administrative labor costs, the contracting officer should keep a record of:
(i) Name, position, and organization of each employee performing work activities as a consequence of the default;
(ii) Dates of work and time spent by each employee on the repurchase;
(iii) Specific tasks performed (e.g., solicitation preparation, clerical);
(iv) Hourly rates of pay (straight time or overtime); and
(v) Applicable fringe benefits.
(2) Travel vouchers, invoices, printing requisitions, and other appropriate evidence of expenditures may be used to support other administrative costs (e.g., travel, per diem, printing and distribution of the repurchase contract).
(c) If assessment of administrative costs is considered appropriate after review by the AGC, the contracting officer shall make a written demand on the contractor for administrative costs. The written demand shall describe the basis for the assessment and the cost computations. The same demand letter may be used to assess administrative costs and any excess costs. If the contractor fails to make payment after receiving a contracting officer's final decision, the contracting officer shall follow the procedures in subpart 1332.6 and FAR Subpart 32.6 to collect the amount owed the Government.
(d) The recovery of excess or administrative costs does not preclude the Government from exercising other rights or remedies which it may have by law or under the terminated contract.
Federal Property and Administrative Services Act of 1949, as amended (40 U.S.C. 486(c)), as delegated by the Secretary of Commerce in Department Organization Order 10-5 and Department Administrative Order 208-2).
This part implements and supplements FAR Part 52 by prescribing specific modifications, alterations, and deviations to FAR solicitation provisions and contract clauses for Department-wide use.
The Department's policy is to use the FAR and CAR prescribed solicitation provisions and contract clauses unless specific authority for deviations has been obtained. (See 1301.4 for authority to deviate.) The use of uniform solicitation provisions and contract clauses should: provide a less burdensome way for potential contractors to respond to the Government's request for information concerning the evaluation of bids and proposals; expedite solicitation and contract preparation; and facilitate contract negotiation, administration and review. Each solicitation which incorporates contract clauses or solicitation provisions which deviate from those prescribed by the FAR and the CAR must be submitted to the Office of Procurement and Federal Assistance for prior review. The Office of Procurement and Federal Assistance will coordinate requests for approval of these solicitations by the Office of Management and Budget, in accordance with the Paperwork Reduction Act of 1980 and 5 CFR part 1320.
Contracting officers within the Department shall incorporate solicitation provisions and contract clauses by reference in solicitations and contracts to the maximum extent provided by applicable law and regulation. Incorporation by reference is the listing only by title, regulatory citation, and date of the provision or clause rather than the full text. The full text of the referenced solicitation provision or contract clause is contained in the Code of Federal
As prescribed in 1317.7001(a), insert the following clause:
(a) All work and material shall be subject to the approval of the Contracting Officer or his duly authorized representative. Work shall be performed in accordance with the plans and specifications of this contract as modified by any contract modification.
(b) Unless otherwise specifically provided for in the contract, all operational practices of the Contractor and all workmanship and material, equipment and articles used in the performance of work shall be in accordance with American Bureau of Shipping Rules for Building and Classing Steel Vessels, U.S. Coast Guard Marine Engineering Regulations and Material Specifications (Subchapter F 46 CFR), U.S. Coast Guard Electrical Engineering Regulations (Subchapter J 46 CFR) (APR 1982), and U.S.P.H.S., Handbook on Sanitation in Vessel Construction, in effect at the time of the Contractor's submission of bid (or acceptance of the contract, if negotiated), and the best commercial maritime practices, except where military specifications are specified, in which case such standards of material and workmanship shall be followed.
(c) All material and workmanship shall be subject to inspection and test at all times during the Contractor's performance of the work to determine their quality and suitability for the purpose intended and compliance with the contract. In case any material or workmanship furnished by the Contractor is found to be defective prior to redelivery of the vessel, or not in accordanoe with the requirements of the contract, the Government shall have the right prior to redelivery of the vessel to reject such material or workmanship, and to require its correction or replacement by the Contractor at the Contractor's cost and expense. This Government right is in addition to its rights under any Guarantee clause in this contract. If the Contractor fails to proceed promptly with the replacement or correction of such material or workmanship, as required by the Contracting Officer, the Government may, by contract or otherwise, replace or correct such material or workmanship and charge to the Contractor the excess cost to the Government. The Contractor shall provide and maintain an inspection system acceptable to the Government covering the work specified in the contract. Records of all inspection work by the Contractor shall be kept complete and available to the Government during the performance of the contract and for a period of 2 years after delivery of the vessel to the Government.
(d) No welding, including tack welding and brazing, shall be permitted in connection with repairs, completions, alterations, or addition to hulls, machinery or components of vessels unless the welder is at the time, qualified to the standards established by the United States Coast Guard, the American Bureau of Shipping, or the Department of the Navy. The welder's qualifications shall be appropriate for the particular service application, filler material type, position of welding, and welding process involved in the work being undertaken. A welder may be required to requalify if the Contracting Officer believes there is a reasonable doubt concerning the welder's ability. Welder's qualifications for this purpose shall be outlined in “Marine Engineering Regulations” of the United States Coast Guard. When a welding process other than manual shielded arc is proposed or required, the contractor or fabricator shall submit procedure qualification tests for approval prior to production welding. Procedure qualification tests shall be conducted in accordance with the requirements of the “Marine Engineering Regulations” of the United States Coast Guard.
(e) The Contractor shall exercise reasonable care to protect the vessel from fire, and the Contractor shall maintain a reasonable system of inspection over the activities of welders, burners, riveters, painters, plumbers and similar workers, particularly where such activities are undertaken in the vicinity of the vessel's magazine, fuel oil tanks, or storerooms containing flammable material. A reasonable number of hose lines shall be maintained by the Contractor ready for immediate use on the vessel at all times while the vessel is berthed alongside the Contractor's pier or in drydock or on a marine railway. All tanks or bilge areas under alteration or repair shall be cleaned, washed, and steamed out or otherwise made safe by the Contractor if and to the extent necessary as required by good marine practice or by current OSHA Regulations. The Contracting Officer's Technical Representative (COTR) shall be furnished with a “gas free” or “safe for hot work” or “safe for men” certificate before any hot work or entry is done. Unless otherwise provided in this contract, the Contractor shall at all times maintain a reasonable fire watch about the vessel, including a
(f) The Contractor shall place proper safeguards and/or effect such safety precautions as necessary, including suitable and sufficient lighting, for the prevention of accidents or injury to persons or property during the prosecution of work under this contract and/or from time of receipt of the vessel until acceptance by the Government of the work performed.
(g) Except as otherwise provided in this contract, when the vessel is in the custody of the contractor or in drydock or on a marine railway and the temperature becomes as low as 35 degrees Fahrenheit, the Contractor shall keep all pipelines, fixtures, traps, tanks, and other receptacles on the vessel drained to avoid damage from freezing, or if this is not practicable, the vessel shall be kept heated to prevent such damage. The vessel's stern tube and propeller hubs shall be protected from frost damage by applied heat through the use of a salamander or other proper means, as approved by the COTR.
(h) Whenever practicable, the work shall be performed in a manner which does not interfere with the berthing and messing of personnel attached to the vessel. The Contractor shall ensure that assigned personnel have access to the vessel at all times. It is understood that such personnel will not interfere with the work or the Contractor's workers.
(i) The Government does not guarantee the correctness of the dimensions, sizes, and shapes given in any sketches, drawings, plans or specifications prepared or furnished by the Government. The Contractor shall be responsible for the correctness of the shape, sizes and dimensions of parts to be furnished hereunder, other than those furnished by the Government.
(j) The Contractor shall at all times keep the site of the work on the vessel free from accumulation of waste material or rubbish caused by Contractor employees or the work, and at the completion of the work shall remove all rubbish from and about the site of the work and shall leave the work and its immediate vicinity “broom clean” unless more exactly specified in this contract.
(k) While in drydock or on a marine railway, the Contractor shall be responsible for the closing before the end of working hours, of all valves and openings upon which work is being done by its workers when such closing is practicable. The Contractor shall keep the COTR cognizant of the closure status of all valves and openings upon which the Contractor's workers have been working.
(l) Without additional expense to the Government, the Contractor shall employ specialty subcontractors where required by the specifications or when necessary for satisfactory performance of the work.
(m) When requested by the COTR, the Contractor shall notify the COTR in advance:
(i) Prior to starting inspections or tests; and
(ii) When supplies will be ready for Government inspection.
(n) When advance notification is requested, the authorized COTR shall specify the period and method of notification.
As prescribed in 1317.7001(a), insert the following clause:
(a) The Government shall deliver the vessel to the Contractor at the location specified in the contract.
(b) If the Contractor's plant is specified, it shall be understood to mean the fairway of the plant. The Contractor shall provide necessary tugs and pilot services to move the vessel from the fairway to the pier or dock and, upon completion of all work, from the pier or dock to the fairway of the plant.
(c) While the vessel is in the possession of the Contractor, any necessary movement of the vessel incidental to the work specified in the contract shall be furnished by the Contractor without additional charge to the Government.
As prescribed in 1317.7001(a), insert the following clause:
(a) Upon the issuance of the contract, the Contractor shall promptly commence the work specified in any plans and specifications made a part of the contract, and shall diligently prosecute the work to completion. The Contractor shall not commence work until the contract has been issued.
(b) The Government shall deliver the vessel described in the contract at such time and location as may be specified in the contract. Upon completion of the work, the Government shall accept delivery of the vessel at such time and location as may be specified in the contract.
(c) Without additional charge to the Government, and without specific requirement in the contract, the Contractor shall:
(1) Make available at the plant to personnel of the vessel while in drydock or on a marine railway, toilet and similar facilities acceptable to the Contracting Officer as adequate in number and sanitary standards;
(2) Supply and maintain, in such condition as the Contracting Officer may reasonably require, suitable brows and gangways from the pier, drydock or marine railway to the vessel;
(3) Treat salvage, scrap, or other ship's material of the Government resulting from performance of the work as items of Government furnished property in accordance with the Government Property clause;
(4) Perform, or pay the cost of, any repair, reconditioning or replacement made necessary as the result of the use by the Contractor of any of the vessel's machinery, equipment or fittings, including, but not limited to, winches, pumps, riggings, or pipe lines; and
(5) Furnish suitable offices, office equipment and telephones at or near the site of the work as the Contracting Officer reasonably requires for himself and his staff.
(d) Except as otherwise provided in the contract, the Contractor shall furnish all necessary material, labor, services, equipment, supplies, power, accessories, facilities, and other things and services necessary for accomplishing the work, subject to Government rights under the Government Property clause.
(e) The Contractor shall conduct dock and sea trials of the vessel as required by the contract. Unless otherwise expressly provided in the contract, during the conduct of these trials the vessel shall be under the control of the vessel's commander and crew with representatives of the Contractor and the Government on board to determine whether or not the work done by the Contractor has been satisfactorily performed. Dock and sea trials not speoified which the Contractor requires for his own benefit shall not be undertaken by the Contractor without prior notice to and approval of the Contracting Officer; any such dock or sea trial shall be conducted at the risk and expense of the Contractor. The Contractor shall provide and install all fittings and appliances which may be necessary for the dock and sea trials, to enable the representatives of the Government to determine whether the requirements of the contract plans and specifications have been met. The Contractor shall also be responsible for the care, installation and removal of any instruments and apparatus furnished by the Government for such trials.
As prescribed in 1317.7001(a), insert the following clause:
When during the performance of this contract the Contractor is required to delay the work on a vessel temporarily, due to orders or actions of the Government respecting stoppage of work to permit shifting the vessel, stoppage of hot work to permit bunkering, fueling, stoppage of work due to embarking or debarking passengers and loading or discharging cargo, and the Contractor is not given sufficient advance notice or is otherwise unable to avoid incurring additional costs on account thereof, an equitable adjustment may be made in the contract price pursuant to the Changes clause.
As prescribed in 1317.7001(a), insert the following clause:
(a) In order to assure timely delivery of the vessel under this contract, it is imperative that delay in delivery of such vessel resulting from late, damaged, or unsuitable Government furnished property be held to an absolute minimum. In order to achieve minimization of delay it is agreed that:
(1) Subject to adjustment as provided in paragraph (b) of this clause, the Government shall deliver each item of Government furnished property to the Contractor on or before the date specified in the contract or, if later, in sufficient time for the contractor to deliver the vessel in accordance with the delivery schedule specified elsewhere.
(2) The Government may forego furnishing any item of Government property to the Contractor. In that event, the Contractor shall prepare the vessel in terms of piping, wiring, structure, foundation, ventilation, and any other preinstallation requirements of the item, so that the work on the vessel may continue without delay and disruption resulting from the absence of the item. If the Government does not furnish an item designated as Government furnished property, the parties may be entitled to an equitable adjustment in the contract price, in accordance with the Changes clause for eliminating the requirement to install the Government property item. But, notwithstanding any other clause of this contract, an adjustment shall not be made in the delivery schedule of any vessel if the Government chooses not to furnish the item on or before the delivery date of the item. If the Government subsequently desires the Contractor to install the item prior to delivery of the vessel, a contract modification shall be executed which takes into account any increase in cost or performance time resulting from the installation.
(b) If the delivery date for the vessel is extended for any reason, the latest date for
(c) The delivery or performance dates for the supplies or services to be furnished by the Contractor under this contract are based upon the expectation that Government furnished property suitable for use (except for such property furnished “as is”) will be delivered to the Contractor at the time stated in the specification or, if not so stated, in sufficient time to enable the Contractor to meet such delivery or performance dates. If the Government furnished property is not delivered to the Contractor by such time and the Contractor makes a timely written request, the Contracting Officer shall determine if an equitable adjustment is appropriate. If determined appropriate, the Contracting Officer shall equitably adjust the delivery or performance date, the specifications, the price, or any other contractual provision affected by any such delay, in accordance with the Changes clause.
(d) The Government Property and Minimization of Delay Due to Government Furnished Property clauses contain exclusive remedies. The Government shall not be liable to suit for breach of contract by reason of any delay in delivery of Government furnished property or delivery of such property in a condition not suitable for its intended use.
As prescribed in 1317.7001(a), insert the following clause:
(a) Notwithstanding any requirements to the contrary for the furnishing of material by the Government which may appear in plans, drawings, or other data, the Government shall furnish only the material specifically listed in the specifications as Government furnished property. Any material required for the performance of the contract which does not appear in the specifications as Government furnished shall be furnished by the Contractor.
(b) The Contracting Officer may increase the amount of material to be furnished by the Government and the contract shall be equitably adjusted in accordance with the Government Property clause.
(c) Unless otherwise specifically directed by the Contracting Officer, nonreusable crates and other nonreusable packaging in which Government material is delivered to the Contractor shall become the property of the Contractor upon removal of the packaged or crated material.
(d) Any packaging in preparation for delivery or for other disposal of Government property by the Contractor at the direction or authorization of the Contracting Officer pursuant to paragraph (i) of the Government Property clause shall be provided for by change order and an appropriate adjustment shall be made in the contract price in accordance with the Changes clause.
(e) The vessel, its equipment, movable stores, cargo and other ship's material are not designated Government furnished property under the Government Property clause.
As prescribed in 1317.7001(a), insert the following clause:
(a) The Contractor shall exercise reasonable care and use its best efforts to prevent accidents, injury or damage to all employees, persons and property, in and about the work, and to the vessel or part thereof upon which work is done.
(b) The Contractor shall be responsible for and make good at its own cost and expense any and all loss of or damage of whatsoever nature to the vessel (or part thereof), its equipment, movable stores and cargo, and Government owned material and equipment for the repair, completion, alteration of or addition to the vessel in the possession of the Contractor, whether at the plant or elsewhere, arising or growing out of the performance of the work, except where the Contractor can affirmatively show that such loss or damage was due to causes beyond the Contractor's control, was proximately caused by the fault or negligence of agents or employees of the Government, or which loss or damage the Contractor by exercise of reasonable care was unable to prevent. However, the Contractor shall not be responsible for any such loss or damage discovered after redelivery of the vessel unless (i) the loss or damage is discovered within 90 days after redelivery of the vessel and (ii) loss or damage is affirmatively shown to be the result of the fault or negligence of the Contractor. To induce the Contractor to perform the work for
(c) The Contractor indemnifies and holds harmless the Government, its agencies and instrumentalities, and the vessel against all suits, actions, claims, costs or demands (including without limitation, suits, actions, claims, costs or demands resulting from death, personal injury and property damage) to which the Government, its agencies and instrumentalities, or the vessel may be subject or put by reason of damage or injury (including death) to the property or person of any one other than the Government, its agencies, instrumentalities and personnel, or the vessel arising or resulting in whole or in part from the fault, negligence, wrongful act or wrongful omission of the Contractor, or any subcontractor, its or their servants, agents or employees; provided that the Contractor's obligation to indemnify under this paragraph (c) shall not exceed the sum of $300,000 on account of any one accident or occurrence in respect of any one vessel. Such indemnity shall include, without limitation, suits, actions, claims, costs or demands of any kind whatsoever, resulting from death, personal injury or property damage occurring during the period of performance of work on the vessel or within 90 days after redelivery of the vessel. With respect to any such suits, actions, claims, costs or demands resulting from death, personal injury or property damage occurring after the expiration of such period, the rights and liabilities of the Government and the Contractor shall be as determined by other provisions of this contract and by law; provided that such indemnity shall apply to death occurring after such period which results from any personal injury received during the period covered by the Contractor's indemnity as provided herein.
(d) The Contractor shall, at its own expense, procure, and thereafter maintain such casualty, accident and liability insurance, in such forms and amounts as may be approved by the Contracting Officer, insuring the performance of its obligations under paragraph (c) of this clause. In addition, the Contractor shall at its own expense procure and thereafter maintain such ship repairer's legal liability insurance as may be necessary to insure the Contractor against its liability as ship repairer in the amount of $300,000, or the value of the vessel as determined by the Contracting Officer, whichever is the lesser, with respect to each vessel on which work is performed. The Contractor shall cause the Government to be named as an additional insured under any and all liability insurance policies. However, at the discretion of the Contracting Officer, such insurance need not be procured whenever the job order requires work on parts of a vessel only and the work is to be performed at a plant other than the site of the vessel. Further, the Contractor shall procure and maintain in force Workmen's Compensation Insurance (or its equivalent) covering its employees engaged in the work and shall insure the procurement and maintenance of such insurance by all subcontractors engaged in the work. The Contractor shall provide evidence of insurance as required by the Government.
(e) The Contractor shall receive no allowance in the contract price for inclusion of any premium expense or charge for any reserve made on account of self-insurance for coverage against any risk assumed by the Government under this clause.
(f) As soon as practicable after the occurrence of any loss or damage the risk of which the Government has assumed, written notice of the damage shall be given by the Contractor to the Contracting Officer. The notice shall contain full particulars of the loss or damage. If claim is made or suit is brought thereafter against the Contractor as the result or because of such event, the Contractor shall immediately deliver to the Government every demand, notice, summons or other process received by it or its representatives. The Contractor shall cooperate with the
As prescribed in 1317.7001(a), insert the following clause:
Unless title to materials and equipment acquired or produced for, or allocated to, the performance of this contract shall have vested previously in the Government by virtue of other provisions of this contract, title to all materials and equipment to be incorporated in any vessel or part thereof, or to be placed upon any vessel or part hereof in accordance with the requirements of the contract, shall vest in the Government upon delivery thereof at the plant or such other location as may be specified in the contract for the performance of the work. However, the Contractor is fully responsible for all such Contractor furnished materials and equipment or the restoration of any damaged work. It is expressly understood and agreed that the Contractor shall assume without limitation the risk of loss for any such materials and equipment until such time as all work is completed and accepted by the Government and the vessel is redelivered to the Government. Upon completion of the contract, or with the approval of the Contracting Officer at any time during the performance of the contract, all such Contractor furnished materials and equipment not incorporated in any vessel or part thereof, or not placed upon any vessel or part thereof, in accordance with the requirements of the contract, shall become the property of the Contractor, except those materials and equipment the cost of which has been reimbursed by the Government to the Contractor.
As prescribed in 1317.7001(a), insert the following clause:
The Contractor shall immediately discharge or cause to be discharged any lien or right in rem of any kind, other than in favor of the Government, which at any time exists or arises in connection with work done or materials furnished under any contract hereunder with respect to the machinery, fittings, equipment or materials for any of the vessels. If any such lien or right in rem is not immediately discharged, the Government may discharge or cause to be discharged such lien or right at the expense of the Contractor.
As prescribed in 1317.7001(a), insert the following clause:
Attention of the Contractor is directed to the Occupational Safety and Health Act of 1970 (29 U.S.C. 651-678), and to the Occupational Safety and Health Standards for Shipyard Employment (29 CFR 1915), promulgated under Pub. L. 85-742, amending Section 41 of the Longshoremen's and Harbor Workers’ Compensation Act (33 U.S.C. 941), and adopted by the Department of Labor as occupational safety or health standards under Section 6(a) of the Occupation Safety and Health Act of 1970 (29 CFR 1910.13). These regulations apply to all ship repair and related work, as defined in the regulations, performed under this contract on the navigable waters of the United States, including any dry dock or marine railway. Nothing contained in this contract shall be construed as relieving the Contractor from any obligations which it may have for compliance with the aforesaid regulations.
As prescribed in 1317.7001(a), insert the following clause:
If asbestos is encountered, the Contractor shall follow the regulations contained in 29 CFR 1910.1001 (OSHA, Chapter XVII).
As prescribed in 1317.7001(a), insert the following clause:
Whenever the Contractor submits any claim for an equitable adjustment attributable to any fact or circumstance regarded as a change order whether formal or “constructive,” under the Changes clause or any other clause of this contract, such claim shall include all adjustments (including but not limited to adjustments arising out of delays or disruptions or both caused by such change order) to which the Contractor is entitled under this contract. The foregoing requirement shall not preclude the Contractor from revising or resubmitting the claim prior to agreement upon the equitable adjustment for the change order. However, unless otherwise expressly agreed in the aforesaid supplemental agreement, the Contractor shall waive any right under the Changes clause or any other clause of this contract to further equitable adjustments attributable to such facts or circumstances giving rise to the claim upon the execution of the supplemental agreement setting forth the equitable adjustment. In any event, such right shall be deemed to be waived.
As prescribed in 1317.7001(a), insert the following clause:
(a) Documentation, including drawings and other engineering products and reports, required by the contract to be submitted for review, comment, acceptance or approval will be acted upon by the Government within 30 calendar days after receipt by the Government, unless another period of time is specified.
(b) Review, comment, acceptance or approval by the Government as required under this contract and applicable specifications shall not relieve the Contractor of its obligation to comply with the specifications and with all other requirements of the contract, nor shall it impose upon the Government any liability it would not have had in the absence of such review, comment and acceptance or approval.
As prescribed in 1317.7001(a), insert the following clause:
(a) As authorized by the Contracting Officer, a reasonable number of officers, employees and associates of the Government, or other prime Contractors with the Government and their subcontractors shall have admission to the plant and access to the vessel(s) at all reasonable times to perform and fulfill their respective obligations to the Government on a noninterference basis. The Contractor shall make reasonable arrangements to provide access for these personnel to office space, work areas, storage or shop areas, and other facilities and services, reasonable and necessary to performance of their respective duties. All such personnel shall comply with Contractor rules and regulations governing personnel at its shipyard, including those regarding safety and security.
(b) The Contractor further agrees to allow a reasonable number of officers, employees, and associates of offerors on other contemplated work, the same privileges of admission to the Contractor's plant and access to the vessel(s) on a noninterference basis subject to Contractor rules and regulations governing personnel in its shipyard, including those regarding safety and security.
As prescribed in 1317.7001(a), insert the following clause:
(a) For the purpose of this clause, the term “change” includes not only a change made pursuant to a written order designated as a “change order” but also any act or omission to act on the part of the Government where a request is made for equitable adjustment.
(b) Whenever the Contractor requests or proposes an equitable adjustment to the contract price of not more than $100,000, for a change or an act or omission on the part of the Government, the request shall include a breakdown of the price adjustment in such form and supported by such reasonable detail as the Contracting Officer may request. As a minimum, the Contractor shall provide a breakdown of direct labor hours, labor dollars, overhead, material, subcontracts, contingencies and profit for each change and a
(c) Whenever the Contractor requests or proposes an equitable adjustment of $100,000 gross (aggregate increases and/or decreases) or more to the price of the contract for a change made pursuant to a written order designated as a “change order” or whenever the Contractor requests an equitable adjustment in any amount for any other act or omission to act on the part of the Government, the proposal supporting such request shall contain the following information for each individual item or element of the request:
(1) A description of (i) the unperformed work required by the contract before the change which has been deleted by the change and (ii) the work deleted by the change that already has been completed in whole or in part. The description shall include a list of components, equipment, and other identifiable property involved. Also, the status of manufacture, procurement, or installation of such property shall be indicated. A separate description shall be furnished for design and production work. Items of raw material, purchased parts, components, and other identifiable hardware which are made excess by the change, and which are not to be retained by the Contractor, are to be listed for later disposition;
(2) A description of the work necessary to undo work already completed which has been deleted by the change;
(3) A description of the work substituted or added by the change that was not required by the terms of the contract before the change. A list of components and equipment (not bulk material or items) involved, should be included. A separate description shall be furnished for design work and production work;
(4) A description of any interference or inefficiency encountered in performing the change;
(5) A description of disruption attributable solely to the change, which shall include the following information:
(i) A specific description of each element of disruption which states how the work has been, or will be, disrupted;
(ii) The calendar time period when disruption occurred, or will occur;
(iii) The area(s) aboard ship where disruption occurred, or will occur;
(iv) The trade(s) disrupted, with a breakdown of man-hours for each trade;
(v) The scheduling of trades before, during, and after the period of disruption;
(vi) A description of measures taken to lessen the disruptive effect of the change.
(6) The delay in delivery attributable solely to the change;
(7) A description of other work attributed to the change;
(8) A narrative statement of the direct causal relationship between any alleged Government act or omission and the claimed result, cross-referenced to the detailed information required above.
(9) A statement setting forth a comparative enumeration of the amounts “budgeted” for the cost elements, including the materials cost, labor hours, and indirect costs pertinent to the change estimated by the Contractor in preparing his initial and ultimate proposal(s) for this contract, and the amounts claimed to have been incurred, or projected to be incurred, corresponding to each such “budgeted cost” element.
(d) In addition to the information required by paragraph (b), each proposal submitted in support of a claim for equitable adjustment in the amount of $100,000 or more under any provision of this contract shall contain a duly executed Standard Form 1411 (Contract Pricing Proposal) for each individual claim item. The submitted Standard Form 1411 shall fully comply with Section 15.804-6 of the Federal Acquisition Regulation and any instructions on the reverse side of the form.
(e) In addition to the information required by paragraph (c), each proposal submitted in support of a claim for equitable adjustment under any provision of this contract shall contain a duly executed SF-1411 (Contracting Pricing Proposal) for each individual claim item. The submitted SF-1411 shall fully comply with Section 15.804-6 of the Federal Acquisition Regulation and any instructions on the reverse side of the form.
(f) Individual claims for equitable adjustment may not encompass all of the factors listed in (c) above. Accordingly, the Contractor is required to set forth in his proposal information only with respect to those factors which are encompassed in the individual claim for equitable adjustment. In any event, the information furnished hereunder shall be in sufficient detail to permit the Contracting Officer to correlate the claimed increased costs or delay in delivery set forth in the SF-1411 (Contracting Pricing Proposal) with the information submitted pursuant to paragraph (c).
As prescribed in 1317.7001(a), insert the following clause:
(a)(1) In addition to issuing changes under the Changes clause, the Contracting Officer may propose changes within the general scope of this contract, as set forth below. Within 10 days from the date of receipt of any such proposed change, or within such further time as the Contracting Officer may
(2) The Contractor's estimate shall be a firm offer for 30 days from receipt thereof by the cognizant Contracting Officer, unless extended by mutual consent. Within the time limit, the Contractor agrees to either (i) enter into a supplemental agreement covering the estimate as submitted or (ii) begin good faith negotiations at the request of the Contracting Officer, leading to the execution of a bilateral supplemental agreement, if the estimate as submitted is not satisfactory to the Contracting Officer. In either case, the supplemental agreement shall include an equitable adjustment for the preparatory work set forth above.
(b) Pending execution of a bilateral agreement or the direction of the Contracting Officer pursuant to the Changes clause, the Contractor shall proceed diligently with contract performance without regard to the effect of any such proposed change.
(c) Concurrently with the submission of any Change Proposal under this contract in which the proposed aggregate cost is $100,000 or greater, the Contractor shall submit to the Contracting Officer a completed Standard Form 1411. At the time of agreement upon the price of the Change Proposal, the Contractor shall submit a signed Certificate of Current Cost or Pricing Data.
As prescribed in 1317.7001(a), insert the following clause:
(a) Lay day time will be paid for by the Government at the Contractor's stipulated bid price for this item of the contract when the vessel remains on the dry dock or marine railways as a result of any Government change that involves work in addition to that required under the basic contract.
(b) No amount for lay day time shall be paid until all accepted items of the basic contract for which a price was established by the Contractor and for which docking of the vessel was required have been satisfactorily completed.
(c) Days of hauling out and floating, whatever the hour, shall not be paid as lay day time, and days when no work is performed by the Contractor shall not be paid as lay day time.
(d) Payment of lay day time shall constitute complete compensation for all costs except for the direct cost of performing the changed work.
As prescribed in 1317.7001(a), insert the following clause:
(a) The Contracting Officer may at any time, by written order, and without notice to the sureties, if any, make changes within the general scope of this contract, in any one or more of the following:
(1) Drawings, designs, or specifications, when the supplies to be furnished are to be specially manufactured for the Government in accordance with the drawings, designs, or specifications;
(2) Method of shipment or packing;
(3) Place of performance of the work;
(4) Time of commencement or completion of the work; and
(5) Other requirements within the general scope of the contract.
(b) If any such change causes an increase or decrease in the cost of, or the time requried for, performance of any part of the work under this contract, whether changed or not changed by the order, the Contracting Officer shall make an equitable adjustment in the contract price, the delivery schedule, or both, and shall modify the contract.
(c) The Contractor must submit any proposal for adjustment (hereafter referred to as proposal) under this clause within 10 days from the date of receipt of the written order. However, if the Contracting Officer decides that the facts justify it, the Contracting Officer may receive and act upon a proposal submitted before final payment of the contract.
(d) If the Contractor's proposal includes the cost of property made obsolete or excess by the change, the Contracting Officer shall have the right to prescribe the manner of the disposition of the property.
(e) Failure to agree to any adjustment shall be a dispute under the Disputes clause. However, nothing in this clause shall excuse the Contractor from proceeding with the contract as changed.
As prescribed in 1317.7001(a), insert the following clause:
(a) The Government may, subject to paragraphs (c) and (d) of this clause, by written notice of default to the Contractor, terminate this contract in whole or in part if the Contractor fails to—
(1) Deliver the supplies or to perform the services within the time specified in this contract or any extension;
(2) Make progress, so as to endanger performance of this contract; or
(3) Perform any of the other provisions of this contract.
(b) If the Government terminates this contract in whole or in part, it may arrange for completion of the work in the manner the Contracting Officer considers appropriate. The Contracting Officer may designate any plant or plants for completion of the work, including the Contractor's plant or plants. If the work is to be completed at the Contractor's plant, the Government may use all tools, machinery, facilities and equipment of the Contractor which the Contracting Officer determines to be necessary. The Contractor will be liable to the Government for any excess costs, other than those costs attributable to changes in the plans or specifications made after the termination date. However, the Contractor shall continue the work not terminated.
(c) Except for defaults of subcontractors at any tier, the Contractor shall not be liable for any excess costs if the failure to perform the contract arises from causes beyond the control and without the fault or negligence of the Contractor. Examples of such causes include (1) acts of God or of the public enemy, (2) acts of the Government in either its sovereign or contractual capacity, (3) fires, (4) floods, (5) epidemics, (6) quarantine restrictions, (7) strikes, (8) freight embargoes, and (9) unusually severe weather. In each instance the failure to perform must be beyond the control and without the fault or negligence of the Contractor.
(d) If the failure to perform is caused by the default of a subcontractor at any tier, and if the cause of the default is beyond the control of both the Contractor and subcontractor, and without the fault or negligence of either, the Contractor shall not be liable for any excess costs for failure to perform, unless the subcontracted supplies or services were obtainable from other sources in sufficient time for the Contractor to meet the required delivery schedule.
(e) If this contract is terminated for default, the Government may require the Contractor to transfer title and deliver to the Government, as directed by the Contracting Officer, any (1) completed supplies, and (2) partially completed supplies and materials, parts, tools, dies, jigs, fixtures, plans, drawings, information, and contract rights (collectively referred to as “manufacturing materials” in this clause) that the Contractor has specifically produced or acquired for the terminated portion of this contract. Upon direction of the Contracting Officer, the Contractor shall also protect and preserve property in its possession in which the Government has an interest.
(f) The Government shall pay contract price for completed supplies delivered and accepted. The Contractor and Contracting Officer shall agree on the amount of payment for manufacturing materials delivered and accepted and for the protection and preservation of the property. Failure to agree will be a dispute under the Disputes clause. The Government may withhold from these amounts any sum the Contracting Officer determines to be necessary to protect the Government against loss because of outstanding liens or claims of former lien holders.
(g) If, after termination, it is determined that the Contractor was not in default, or that the default was excusable, the rights and obligations of the parties shall be the same as if the termination had been issued for the convenience of the Government.
(h) The rights and remedies of the Government in this clause are in addition to any other rights and remedies provided by law or under this contract.
As prescribed in 1317.7001(b), insert the following clause:
(a) The Contractor shall procure and thereafter maintain the following insurance:
(1) Ship repairer's legal liability insurance to insure the risks described in paragraph (b) of the Liability and Insurance clause. This insurance shall be for $300,000.
(2) Comprehensive general liability insurance and automobile insurance to insure the risks described in paragraph (c) of the Liability and Insurance clause. This insurance shall be for $300,000 on account of any one accident or occurrence with respect to each vessel, boat, and/or barge upon which work is performed. The Contractor shall cause the Government to be named as an additional insured under any and all liability insurance policies.
(3) Full coverage in accordance with the State Workmen's Compensation law; and
(4) Full coverage in accordance with the United States Longshoremen's and Harbor Worker's Act.
(b) As evidence that it has obtained the insurance specified in (a) above, the Contractor shall furnish the Contracting Officer with a certificate or certificates executed by
“It is agreed that in the event of cancellation, or any material change in the policy adversely affecting the interest of the Government in this insurance 30 days prior written notice will be given to the Contracting Officer.”
As prescribed in 1317.7001(c), insert the following clause:
In case any work done or materials furnished by the Contractor under this contract on or for any vessel or the equipment thereof shall, within 90 days from the date of redelivery of the vessel by the Contractor, prove defective or deficient, such defects or deficiencies shall, as required by the Government in writing, be corrected and repaired by the Contractor or at Contractor expense to the satisfaction of the Contracting Officer. However, the Government shall be entitled to rely upon any guarantee secured by the Contractor or any subcontractor covering work done on materials furnished which exceeds the 90-day period until the expiration. Also, with respect to any individual work item identified and listed as incomplete at the redelivery of the vessel, the guarantee period shall run from the date of completion of such item. If and when practicable, the Government shall afford the Contractor an opportunity to effect such corrections and repairs itself. But, when it is impracticable or undesirable to return it to the Contractor, or the Contractor fails to proceed promptly with any such repairs as directed by the Contracting Officer, the corrections and repairs shall be made at Contractor expense at other Government designated locations. Where corrections and repairs are to be made by other than the Contractor, due to non-return of the vessel to the Contractor, the Contractor's liability may be discharged by an equitable deduction in the price of the contract. The Contractor's liability shall only extend for an additional 90-day guarantee period on those defects or deficiencies which it corrected and in no event to those for which payment was made. However, this clause does not limit the responsibility or relieve the liability of the Contractor under the Liability and Insurance clause. At the Contracting Officer's option, defects and deficiencies may be left in their uncorrected condition. In that event, the Contractor and the Contracting Officer shall agree on an equitable deduction from the contract price. If the Contractor and the Contracting Officer fail to agree upon an equitable deduction from the contract price, the dispute shall be determined in accordance with the Disputes clause.
As prescribed in 1317.7001(d), insert the following clause:
(a) Temporary services are services incidental to the performance of work which are required in the schedule or specifications to be provided by the contractor. Temporary services may include the furnishing of water, electricity, telephone service, toilet facilities, garbage removal, office space, parking places, or similar facilities as specified in the schedule or specifications.
(b) If performance time is extended due to Government caused delay or causes beyond the control of both the contractor and subcontractor, and without the fault or negligence of either, the contractor shall have the right to request an equitable adjustment for providing temporary services in excess of the number of estimated days contained in the schedule. Any such equitable adjustment shall not exceed the amount obtained by multiplying the number of excess days by the contractor's unit price contained in the schedule for this item.
As prescribed in 1317.7001(e), insert the following provision:
An offeror who proposes to self-insure for any or all of the risks set forth in the Liability and Insurance clause and the Insurance Requirements clause shall submit satisfactory evidence to permit the Contracting Officer to determine that the offeror's assets are sufficient for the risks set forth in such clauses. The offeror shall submit with its offer 2 certified copies of documents listing
As prescribed in 1319.7003, insert the following provision:
The contractor agrees to develop a list of qualified bidders that are women-owned small businesses. The Small Business Administration Procurement and Automated Source System (PASS) and the Minority Vendor Profile System (MVPS) may be used for this purpose. The contractor may contact the Department of Commerce, Office of Small and Disadvantaged Business Utilization (OSDBU) for assistance.
The Contractor shall provide opportunities for women-owned small businesses to compete for subcontracts by making information on forthcoming opportunities available.
Where the clause “Small Business and Small Disadvantaged Business Subcontracting Plan” is required in accordance with FAR 19.708(b), the contractor shall include qualified women-owned small businesses in the subcontracting plan.
As prescribed in 1333.106, insert the following provision:
Protests, as defined in 33.101 of the Federal Acquisition Regulation, shall be served on the Contracting Officer and the Contract Law Division of the Office of the Assistant General Counsel for Finance and Litigation by obtaining written and dated acknowledgement of receipt from the Contracting Officer or the head of the contracting office or designee and from the Contract Law Division of the Office of the Assistant General Counsel for Finance and Litigation located at the U.S. Department of Commerce, Herbert C. Hoover Building, Room H5882, 14th St. between Pennsylvania and Constitution Avenues, NW., Washington, DC 20230.
[Insert the address of the contracting officer or refer to the number of the block on the Standard Form 33 or 1442, etc., where the address of the contracting offfice is located.]
Federal Property and Administrative Services Act of 1949, as amended (40 U.S.C. 486(c)), as delegated by the Secretary of Commerce in Department Organization Order 10-5 and Department Administrative Order 208-2.
This part supplements FAR Part 53 by prescribing specific exceptions to FAR prescribed forms for Department-wide use.
The Department's policy is to use the FAR and CAR prescribed forms unless prior specific authority for exceptions or alterations has been obtained. Requests for exceptions to FAR or CAR forms shall be submitted to the Office of Procurement and Federal Assistance in the form prescribed by FAR 53.103 (See 1301.4 for authority to deviate).
This subpart prescribes forms for Department-wide use which are exceptions to FAR prescribed forms. This subpart is arranged by subject matter, in the same order and keyed to the parts of the FAR or CAR in which the form use requirements are addressed.
(a)
(e)
(1) To accomplish small purchases
(2) To issue orders under basic ordering agreements
(3) To issue orders for paid advertisements
(4) To issue orders for construction or dismantling, demolition, or removal of improvements.
A Department approved procurement request form certifies the availability of adequate funds for contract actions (See FAR 32.702). The Department's procurement request form also transmits technical and other specifications of the request, administrative approvals and clearances, and information for processing payments.
Appendix A published at 49 FR 12967, Mar. 30, 1984 and confirmed at 51 FR 1377, Jan. 13, 1986, does not appear in the Code of Federal Regulations. For