Sec. 205(c), 63 Stat. 390, as amended, 40 U.S.C. 486(c).
The Contracting Officer shall insert in the
(a) Use (except for manufacture) by support service contractors;
(b) Evaluation by nongovernment evaluators;
(c) Use (except for manufacture) by other contractors participating in the Government's program of which the specific contract is a part, for information and use in connection with the work performed under each contract;
(d) Emergency repairs or overhaul work;
(e) Release to a foreign government, or instrumentality thereof, as the interests of the United States Government may require, for information or evaluation, or for emergency repair or overhaul work by such government.
The Contracting Officer shall insert the clause in 1552.227-76 in all Superfund solicitations and contracts in excess of the simplified acquisition threshold and, as appropriate, in simplified acquisition procedures. The clause may be used in other contracts if considered necessary by the Contracting Officer.
Sec. 205(c), 63 Stat. 390, as amended, 40 U.S.C. 486(c).
Contractors are responsible for determining the availability of State and local tax exemptions and obtaining such exemptions, if available, unless the Contracting Officer determines under FAR 31.205-41(b)(3) that the administrative burden outweighs the corresponding benefit. Contractors are responsible for ensuring that subcontractors also seek and obtain such exemptions, if available.
Contracting Officers shall insert the clause at 1552.229-70 in all solicitations and contracts when it is anticipated a cost-reimbursable type contract shall be used or a contractor or subcontractor shall be reimbursed for materials at cost.
Sec. 205(c), 63 Stat. 390, as amended, 40 U.S.C. 486(c).
Progress payments based on a percentage or stage of completion are authorized for use as a payment method under EPA contracts or subcontracts for construction and alteration or repair of buildings, structures, or other real property.
The Contracting Officer shall insert the clause at 1552.232-73, Payments—Fixed Rate Services Contract, in solicitations and indefinite delivery/indefinite quantity contracts when services are being acquired on a fixed-rate basis.
(a) EPA Form 1900-10 Contractor's Cumulative Claim and Reconciliation, at 1553.232-74, shall be used for an accounting of the cumulative charges and costs for cost-reimbursement contracts from inception of the contract to completion. It shall be submitted by the Contractor upon submission of the completion voucher.
(b) EPA Form 1900-68, Notice of Contract Costs Suspended and/or Disallowed, at 1553.232-75, shall be inserted in all cost-reimbursement type and fixed-rate type contracts.
Authority for making the determination under FAR 32.201 is delegated to a level above the Contracting Officer.
(a) EPA Form 1900-3, Assignee's Release, at 1553.232-70 is required to be submitted by the assignee for cost-reimbursement contracts prior to final payment under the contract.
(b) EPA Form 1900-4, Assignee's Assignment of Refunds, Rebates, Credits, and Other Amounts, at 1553.232-71 must accompany the assignee's release prior to final payment under cost-reimbursement contracts.
(c) EPA Form 1900-5, Contractor's Assignment of Refunds, Rebates and Credits, at 1553.232-72 must be prepared
(d) EPA Form 1900-6, Contractor's Release, at 1553.232-73 must be submitted by the Contractor prior to final payment under cost-reimbursement contracts.
The Contracting Officer shall insert a clause substantially the same as that at 1552.232-70 in all solicitations and contracts for cost reimbursable acquisitions. If a fixed-rate type contract is contemplated, the Contracting Officer shall use the clause with its Alternate I.
Sec. 205(c), 63 Stat. 390, as amended, 40 U.S.C. 486(c).
Pursuant to an interagency agreement between the EPA and the Department of the Interior Board of Contract Appeals (IBCA), the IBCA will hear appeals from final decisions of EPA Contracting Officers issued pursuant to the Contract Disputes Act. The rules and regulations of the IBCA appear in 43 CFR part 4.
Upon receipt of notice of appeal, the Contracting Officer shall take the following actions:
(a)
(2) A notice of appeal, whether filed within the time prescribed by the “Disputes” clause or not, shall be submitted to the IBCA. The Contracting Officer shall forward promptly every notice of appeal to IBCA even if the intention to appeal is only vaguely or indirectly expressed, and regardless of the form of the notice, or of the method by which the notice was furnished to the Contracting Officer.
(3) Copies of the notice of appeal shall be sent simultaneously to the Quality Assurance Branch, Office of Acquisition Management and to legal counsel.
(b)
(i) The findings of fact and the Contracting Officer's final decision from which the appeal is taken, and the letter or letters or other documents of claim in response to which the decision was issued;
(ii) The contract, and pertinent plans, specifications, amendments, and change orders;
(iii) Correspondence between the parties and other data pertinent to the appeal;
(iv) Transcripts of any testimony taken during the course of proceedings and affidavits, or statements of any witnesses on the matter in dispute
(v) Such additional information as may be considered material.
(2) In addition to the above, the Contracting Officer shall prepare an index listing each document included in the file submitted to the IBCA, and place copies of such index in the submission and duplicate files.
(3) Contracting Officers, in making the submission, may not submit original ducuments which are a part of the official contract file. Copies of the pertinent documents shall be submitted.
(4) Within 15 days of receipt or advice of a notice of appeal, the official and two duplicate files shall be forwarded through legal counsel to the Office of Acquisition Management for review. The Procurement and Contracts Management Division shall forward the official appeal file to the IBCA within the 30 day time limitation set forth in 43 CFR 4.104(a). One duplicate file shall be retained by the Contracting Officer, one by the Procurement and Contracts Management Division, and one by legal counsel.
(5) If for any reason the Contracting Officer anticipates that a timely submission cannot be made, he/she shall immediately advise legal counsel by telephone of the extent of the anticipated delay and the reasons therefor. However, every effort will be exerted to make timely submissions.
(6) At the time of transmittal of the appeal file to the Board, the Contracting Officer shall notify the appellant of the transmittal and provide a copy of the appeal file to the appellant. Within the transmittal to the IBCA, the Contracting Officer shall indicate that the appellant has been provided with a copy of the appeal file.